The URL can be used to link to this page

Home My WebLink AboutTown of Ithaca Town Hall Mezzanine Contract DrawingsN T I O G A S T R E E T N A U R O R A S T R E E T E SENECA STREET AREA OF WORK E BUFFALO STREET ITHACA TOWN HALL ADJACENT BUILDING COORDINATE CONTRACTORS STAGING AREAS IN MECHANICAL ROOM AND OTHER BASEMENT ROOMS WITH OWNERS REPRESENTATIVE. N.I.C. BASEMENT DOOR EXIT EXIT EXIT EXIT EXIT DO NOT OBSTRUCT PASSAGE TO POST OFFICE 8/ 7 / 2 0 2 3 9 : 4 0 : 4 6 A M TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L IT H A C A , N Y CL I E N T P R O J E C T N O : A A 1 6 2 0 . 5 1 7 SET NUMBER: LOCATION MAP PROJECT LOCATION TAITEM ENGINEERING 110 South Albany Street Ithaca, New York 14850 Tel: 607.277.1118 PROJECT NORTH G DISCIPLINE DESIGNATION G = GENERAL H = HAZARDOUS MATERIALS AD = ARCHITECTURAL DEMOLITION A = ARCHITECTURAL PD = PLUMBING DEMOLITION P = PLUMBING MD = MECHANICAL DEMOLITION M = MECHANICAL ED = ELECTRICAL DEMOLITION E = ELECTRICAL FPD = FIRE PROTECTION DEMOLITION FP = FIRE PROTECTION SHEET TYPE 0 = GENERAL 1 = PLANS 2 = ELEVATIONS 3 = SECTIONS 4 = ENLARGED PLANS 5 = DETAILS 6 = WINDOWS SHEET SEQUENCE NO. -0 0 1SHEET NUMBER: NUMBERING CONVENTION DRAWING INDEX NO.SHEET TITLE GENERAL G-001 COVER G-101 CODE DATA, WIND UPLIFT DESIGN CRITERIA, AND GENERAL NOTES HAZARDOUS MATERIALS C-CONTRACT H-101 HAZARDOUS MATERIALS - ABATEMENT ARCHITECTURAL A-001 WALL TYPES AND SCHEDULES AD-101 REMOVALS-FLOOR PLANS AD-111 REMOVALS REFLECTED CEILING PLAN AD-201 REMOVALS-INTERIOR ELEVATIONS A-101 FLOOR PLANS A-102 ATTIC FLOOR PLAN AND SECTION A-111 REFLECTED CEILING PLANS A-201 INTERIOR ELEVATIONS A-301 WALL SECTIONS AND DETAILS A-501 ENLARGED FLOOR PLAN, SECTION AND DETAILS A-601 KEY PLAN AND ELEVATIONS A-602 WINDOW ELEVATIONS A-701 WINDOW AND DOOR DETAILS AND DOOR AND FRAME TYPES PLUMBING P-001 LEGENDS & NOTES PD-101 PLUMBING DEMOLITION PLANS P-101 PLUMBING FLOOR PLANS FIRE PROTECTION FP-001 LEGEND AND NOTES FPD-101 SPRINKLER DEMOLITION PLANS FP-101 SPINKLER FLOORS PLANS MECHANICAL M-001 LEGENDS & NOTES MD-101 MECHANICAL DEMOLITION PLANS M-101 MECHANICAL FLOOR PLANS M-401 SCHEMATICS & DETAILS ELECTRICAL E-001 LEGENDS & NOTES ED-101 ELECTRICAL DEMOLITION PLANS E-101 ELECTRICAL FLOOR PLANS E-102 ELECTRICAL FLOOR PLAN & SCHEMATIC E-111 LIGHTING & FIRE ALARM FLOOR PLANS E-601 PANEL SCHEDULES 1.CONTRACTOR PARKING: 1.1.ON-SITE CONTRACTOR PARKING IS NOT AVAILABLE. 1.2.CONTRACTOR PARKING IS AVAILABLE IN THE NEIGHBORING PARKING GARAGE. PERMITS ARE AVAILABLE FOR PURCHASE FROM CITY OF ITHACA. 2.MATERIAL STAGING & LAYDOWN AREAS AND CRANE ACCESS LOCATIONS ARE INDICATED ON THE DRAWINGS. THE CONTRACTOR SHALL COORDINATE FINAL CRANE STAGING CONTRACTOR STAGING AREA, ACCESS, PARKING, DELIVERY & STORAGE WITH OWNER'S REPRESENTATIVE PRIOR TO MOBILIZATION. 2.1.PROVIDE A CRANE PICK PLAN SUBMITTAL FOR REVIEW FOR ALL CRANE OPERATIONS. INCLUDE CRANE LOADING INFORMATION, OPERATOR CERTIFICATIONS, LAYDOWN AND PICK SITE PLAN FOR ARCHITECT AND OWNER REVIEW PRIOR TO WORK. 2.2.CONTRACTOR TO PROVIDE A FLAGMAN TO DIRECT TRAFFIC WHEN ACCEPTING MATERIAL DELIVERIES OR EQUIPMENT MOVEMENT TO PROVIDE SAFE PASSAGE TO CONSTRUCTION AREAS. TEMPORARY ROAD CLOSURES MUST BE COORDINATED IN ADVANCE. MAINTAIN ROAD ACCESS WIDTH IN ACCORDANCE WITH LOCAL AND STATE REGULATIONS BUT NOT LESS THAN 14'-0” WIDE. 2.3.ANY SIDEWALK OR ROAD CLOSURES MUST BE IN CONFORMANCE WITH THE CITY OF ITHACA REQUIREMENTS AND REGULATIONS, AND ANY NECESSARY PERMITS MUST BE OBTAINED IN ACCORDANCE WITH CITY OF ITHACA REGULATIONS. 3.CONTRACTOR SHALL BARRICADE, IN THE FORM OF A 6'-0” HIGH CHAIN LINK FENCE, THE PERIMETER OF ALL STAGING AREAS TO PREVENT PUBLIC ACCESS. THE BARRICADE SHALL HAVE A LOCKABLE 12'-0” WIDE DOUBLE GATE. 3.1.PROVIDE TEMPORARY WAYFINDING AND CONSTRUCTION CAUTION SIGNAGE TO DIRECT PEDESTRIAN TRAFFIC AROUND BUILDING TO AVAILABLE ENTRANCES; SIGNAGE SIZE: 12”X 24”, COROPLAST BOARD OR OTHER APPROVED MATERIAL, MOUNTED TO TEMPORARY CONSTRUCTION FENCE WITH HEAVY DUTY NYLON CABLE TIES THROUGH (4) EYELETS AT CORNERS. 3.2.PROVIDE INTERIOR SIGNAGE AND THROUGHOUT THE BUILDING DIRECTING PEDESTRIAN TRAFFIC AS NEEDED BASED ON TEMPORARY STAGING TO ALTERNATE EXIT LOCATIONS. 3.3.PROVIDE RUBBER PARKING WHEEL BLOCKS AT ALL ADJACENT PARKING SPACES ABUTTING THE FENCING TO PROTECT FROM IMPACT. 3.4.PROVIDE FENCE SCREENING MOUNTED ON THE INSIDE OF THE FENCE AROUND THE PERIMETER OF ALL STAGING AREAS AND TEMPORARY CONSTRUCTION FENCES. COLOR GREEN VISIBILITY PERCENTAGE 85% OR MORE. 3.5.FENCE POSTS LOCATED IN GRASS AREAS MAY BE DRILLED. POSTS AND BASE OF FENCE ON IMPERVIOUS SURFACES TO BE BALLASTED WITH OUTRIGGERS ADEQUATELY DESIGNED TO WITHSTAND WIND LOADS FROM OVERTURNING THE FENCE. CALL UFPO DIG SAFELY TO SURVEY AND MARK AREA FOR UTILITIES. 4.SITE PLAN INFORMATION IS BASED ON RECORD INFORMATION PROVIDED. NOT ALL EXISTING UTILITIES, TREES, LANDSCAPING, SIDEWALKS, PAVEMENTS, EQUIPMENT, FIXTURES AND TOPOGRAPHIC INFORMATION MAY BE SHOWN. CONTRACTOR SHALL FIELD VERIFY AND FAMILIARIZE THEMSELVES WITH EXISTING CONDITIONS. REPAIR AND RESTORE ANY DAMAGE TO EXISTING CONSTRUCTION AND SITE WORK RESULTING FROM THE WORK OF THIS PROJECT INCLUDING BUT NOT LIMITED TO: GRASSED OR LANDSCAPED AREAS, CURBS, WALKWAYS, CATCH BASINS, PAVEMENT, ETC. CAUSED BY THE WORK OF THIS PROJECT. REPAIRS ARE TO MATCH ORIGINAL/ADJACENT SURFACES UNLESS NOTED OTHERWISE. CONTRACTOR TO TAKE PHOTOGRAPHS OF SITE PRIOR TO START OF WORK AND SUBMIT TO OWNER'S REPRESENTATIVE. 5.EXTERIOR EGRESS PATHS, WALKWAYS AND ENTRANCES SHALL REMAIN UNOBSTRUCTED AND PROTECTED. REFER TO CONSTRUCTION SAFEGUARD NOTES ON G-101. PROVIDE ALTERNATE CIRCULATION AS NEEDED TO ACCESS THE WORK. SITE GENERAL NOTES: PROJECT#: 716-23-002 BID DOCUMENTS 10/24/2025 Fax (315) 487 - 5947 Suite 201 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd Syracuse, NY 13204Pittsford, NY 14534 SCALE:1/64" = 1'-0"1 SITE PLAN 1.PEDESTRIANS AND EGRESS PATHWAYS INCLUDING THE ACCESSIBLE RAMP SHALL REMAIN UNOBSTRUCTED AND PROTECTED DURING THE WORK. 2.CONFORMANCE WITH CHAPTER 15 - CONSTRUCTION SAFEGUARDS OF THE 2020 NYS EXISTING BUILDING CODE AND CHAPTER 33 - SAFGUARDS DURING CONSTRUCTION OF THE 2020 NYS BUILDING CODE CONVEYED IN SITE GENERAL NOTES AND IN THE SITE PLAN ON THIS SHEET (1/COVER). CONTRACTOR MUST COMPLY WITH CHAPTERS 15 OF THE NYSBC, 33 OF THE NYSEBC, AND 33 OF THE NYS FIRE CODE AT ALL TIMES AND IT IS THEIR RESPONSIBILITY TO ENSURE COMPLIANCE. COMPLY WITH THE FOLLOWING MINIMUM REQUIREMENTS: 2.1. OSHA - OCCUPATIONAL SAFETY AND HEALTH ADMINISTRATION. 2.2.2020 BUILDING CODE OF NYS, CHAPTER 33 SAFEGUARDS DURING CONSTRUCTION 2.3.2020 EXISTING BUILDING CODE OF NYS, CHAPTER 15 CONSTRUCTION SAFEGUARDS. 2.4.2020 FIRE CODE OF NYS, CHAPTER 33 FIRE SAFETY DURING CONSTRUCTION AND DEMOLITION. 3.THE BUILDING WILL BE OCCUPIED DURING THE CONSTRUCTION PERIOD. PROVIDE OVERHEAD PROTECTION AT ALL INGRESS/ EGRESS DOORS (ENTRANCES, OVERHEAD DOORS AND EXIT DOORS) IN THE VICINITY OF THE WORK AREA AND MAINTAIN FOR THE DURATION OF THE WORK AS FOLLOWS: A.PROVIDE APPROPRIATE OVERHEAD SCAFFOLDING/BRIDGING FOR OCCUPANTS ENTERING AND EXITING THE BUILDING TO PROTECT FROM FALLING DEBRIS DURING THE WORK. SUCH SCAFFOLDING MAY ALSO DOUBLE FOR CONTRACTOR ACCESS TO THE WORK. STORAGE OF MATERIALS ON SCAFFOLDING SHALL ONLY BE PERMITTED IF THE SYSTEM IS DESIGNED AND ENGINEERED FOR MATERIAL STORAGE. B.CONSTRUCT SYSTEM IN ACCORDANCE WITH NYS UNIFORM FIRE PREVENTION AND BUILDING CODE AND OSHA REGULATIONS. C.WHERE SUBJECT TO IMPACT FROM VEHICLES OR EQUIPMENT, PROVIDE BARRIERS TO PROTECT THE SYSTEMS FROM IMPACT. D.POST TEMPORARY SIGNAGE ON THE PROTECTION COMPONENTS INDICATING WORK IN APPROPRIATE AREAS. E.PROVIDE A MINIMUM 1 FOOTCANDLE (Fc) TEMPORARY CONSTRUCTION LIGHTING AT DOOR LOCATIONS BELOW OVERHEAD PROTECTION SCAFFOLDING. F.SUCH SYSTEMS SHALL BE PREPARED, DESIGNED AND STAMPED BY A NYS LICENSED PROFESSIONAL ENGINEER AND SUBMITTED FOR REVIEW AND APPROVAL. COORDINATE ALL WORK WITH THE OWNER. INCLUDE THE OVERHEAD PROTECTION SYSTEM AS PART OF THE SUBMITTED SAFETY PLAN. G.REPAIR/ RESTORE SYSTEM ANCHORAGE OR ATTACHMENT POINTS ON THE BUILDING. 2.PROVIDE TEMPORARY CONSTRUCTION BARRIERS AT OTHER AREAS AROUND THE WORK AREA TO PROTECT PEDESTRIANS IN ACCORDANCE WITH THE FOLLOWING: CONSTRUCTION SAFEGUARDS NOTES: PROTECTION OF PEDESTRIANS HEIGHT OF CONSTRUCTION DISTANCE OF CONSTRUCTION TO LOT LINE OR WALKWAY TYPE OF PROTECTION REQUIRED MORE THAN 8 FEET LESS THAN 5 FEET 5 FEET OR MORE, BUT NOT MORE THAN ONE-FOURTH THE HEIGHT OF CONSTRUCTION 5 FEET OR MORE, BUT BETWEEN ONE-FOURTH AND ONE-HALF THE HEIGHT OF CONSTRUCTION 5 FEET OR MORE, BUT EXCEEDING ONE-HALF THE HEIGHT OF CONSTRUCTION BARRIER AND OVERHEAD PROTECTION BARRIER NONE (FENCE) PROVIDE OVERHEAD PROTECTION AT ENTRANCE/ EXIT COMPLYING WITH BCNYS CHAPTER 33 SAFEGUARDS DURING CONSTRUCTION AND EBCNYS CHAPTER 15 CONSTRUCTION SAFEGUARDS. BARRIER AND OVERHEAD PROTECTION 1.THIS PROJECT IS DESIGNED IN ACCORDANCE WITH EXISTING 2020 BUILDING CODE AND THE 2020 BUILDING CODE OF NEW YORK STATE (REFERENCING THE 2018 INTERNATIONAL CODES). 2.PER 2020 ECCNYS, C501.6 HISTORIC BUILDINGS: PROVISIONS OF THIS CODE RELATING TO THE CONSTRUCTION, REPAIR, ALTERATION, RESTORATION AND MOVEMENT OF STRUCTURES, AND CHANGE OF OCCUPANCY SHALL NOT BE MANDATORY FOR HISTORIC BUILDINGS. 3.EXPOSED MATERIALS THAT WERE ANTICIPATED TO BE WITHIN THE SCOPE OF THIS PROJECT AT THE TIME OF DESIGN HAVE BEEN TESTED FOR ASBESTOS AND LEAD PAINT CONTENT. SEE THE HAZARDOUS MATERIAL SURVEY REPORT APPENDED TO THE PROJECT MANUAL FOR A LIST OF TESTED MATERIALS. AND THEIR RESULTS. IN SUMMARY, ACM MATERIALS & LEAD BASED MATERIALS ARE ANTICIPATED TO BE DISTURBED. 4.THE SCOPE OF WORK GENERALLY INCLUDES THE FOLLOWING: 4.1.RESTORATION OF HISTORIC WINDOWS. 4.2.INTERIOR INSULATION AT EXTERIOR WALLS. 4.3.UPDATING PUBLIC RESTROOMS FOR ADA CONFORMANCE. 4.4.REMOVAL OF RESTROOM IN COURT CLERK AREA. 4.5.RECONFIGURATION AND HARDENING OF COURT CLERK ENTRANCE. 4.6.RENOVATION OF SECOND FLOOR MEZZANINE, INCLUDING RESTROOM. 4.7.INSULATING THE ATTIC. 4.8.UPDATED LIGHTING IN THE SPACES ABOVE. 4.9.UPDATED MECHANICAL IN THE SPACES ABOVE. 5.THE 1910 & 1935 PORTION OF THE BUILDING IS CONSIDERED HISTORICALLY SIGNIFICANT AND IS LISTED WITH THE NATIONAL REGISTER. WINDOW MODIFICATIONS HAVE BEEN SUBMITTED TO SHPO FOR APPROVAL. 5. WHAT IS REFEREED TO AS "THE MEZZANINE," IS NOT A TRUE MEZZANINE PER CODE. THE TERM IS FOLLOWING THE ORIGINAL BUILDING DRAWINGS. GENERAL DESIGN NOTES: 1000 Mi50200 C - CONTRACT C - CONTRACT P - CONTRACT P - CONTRACT H- CONTRACT E - CONTRACT ALL REGISTRATION EXPIRES: 08/31/2028 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR CABINET M03 TENATE SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM BUILDING CODE SUMMARY DATA BUILDING NAME AND LOCATION TOWN OF ITHACA TOWN HALL 215 NORTH TIOGA STREET ITHACA, NY COUNTY OF TOMPKINS CODE REFERENCE 2020 NYS BUILDING CODE AND / OR 2020 NYS EXISTING BUILDING CODE ITEM (SECTION)EXISTING REQ.PROPOSED REMARKS ALTERATION CLASSIFICATION TYPE (EBCNYS CHAPTER 5) LEVEL 2 USE & OCCUPANCY GROUP (BCNYS CHAPTER 3) B, A & S-1 N/C SPRINKLERED YES N/C CONSTRUCTION TYPE (BCNYS CHAPTER 6) II B N/C N/C BUILDING HEIGHT (BCNYS 504.3) 30'N/C N/C BUILDING AREA (BCNYS 506.2) 20,520 N/C N/C BUILDING NO. STORIES (BCNYS TBL 504.4) 2 N/C N/C MIXED USE AND OCCUPANCIES SEPARATION OF OCCUPANCIES (BCNYS 508.4) NON SEP N/C N/C INCIDENTAL USES (BCNYS 509) N/C N/C N/C ACCESSORY USE AREAS (BCNYS 508.2) N/C N/C N/C SPECIAL USE & OCCUPANCY (BCNYS CHAPTER 4) N/A N/C N/C MEANS OF EGRESS (BCNYS CHAPTER 10) N/C N/C N/C ACCESSIBILITY (BCNYS CHAPTER 11) N/C N/C N/C N/A - NOT APPLICABLE N/C - NO CHANGE N/R - NOT REQUIRED N/P - NOT PROVIDED BUILDING CODE SUMMARY DATA ITEM (SECTION)EXISTING REQ.PROPOSED REMARKS TOTAL OCCUPANT LOAD (BCNYS 1004) 10681 SF/150=71.2= 72 OCC (B) 2984 SF/15=198.9= 199 OCC (A) 13251 SF/300=44.17= 45 OCC (S-1) N/C "2ND FLOOR" OCCUP. LOAD = 6 PPL. OCCUP. LOAD < 50, MEZZ. STAIR WIDTH REQ'D = 36", WIDTH EXISTING = 44" EGRESS WIDTH (BCNYS 1005.2) N/C N/C N/C EGRESS DOOR WIDTH (EBCNYS 1005) 3'-0" MIN.N/C N/C EXIT ACCESS TRAVEL (BCNYS 1017) 113'--SEE 1 & 2/G-101 MIN CORRIDOR WIDTH (BCNYS TBL 1020.2) N/C N/C N/C CORRIDOR FIRE RATING (BCNYS TBL 1020.1) N/C N/C N/C MIN. NUMBER OF EXITS (BCNYS TBL 1006.3.1) 3 -- ACCESSIBILITY (CHAPTER 11) NON-COMFORMING YES YES BATHROOM OFFICE ACCESS N/A - NOT APPLICABLE N/C - NO CHANGE N/R - NOT REQUIRED N/P - NOT PROVIDED TO THE BEST OF THE REGISTERED DESIGN PROFESSIONALS KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGEMENT, THESE PLANS AND/OR SPECIFICATIONS ARE IN COMPLIANCE WITH THE 2020 UNIFORM CODE ECCNYS COMPLIANCE DATA COUNTY CLIMATE ZONE COMMERCIAL / RESIDENTIAL TOMPKINS COUNTY 6 COMMERCIAL COMPLIANCE METHOD (IECC SECTION C401) ECCNYS CHAPTER 4 ENVELOPE SCOPE OF WORK INSULATE EXTERIOR WALLS, RESTORE HISTORIC WINDOWS ITEM (SECTION)EXISTING REQ.PROPOSED REMARKS ROOF INSULATION INSULATION ABOVE ROOF DECK NONE N/C N/C ATTIC INSULATION N/C N/C R-25 WALLS ABOVE GRADE NONE N/C WALLS BELOW GRADE NONE N/C N/C FENESTRATION VERTICAL FENESTRATION (MAX30%)N/C N/C N/C PER EXIST. BLDG ENERGY U-FACTOR (FIXED)N/C 0.36 N/C CODE, WE HAVE MADE A GOOD FAITH TO MEET U-FACTOR (OPERABLE)N/C 0.43 N/C SHGC N/C 0.40 N/C NYSBC BUT GIVEN THE HISTORIC NATURE OF THE BUILDING ALL MIN. MAY NOT BE MET.AIR LEAKAGE N/C N/C N/C VAPOR RETARDER N/C N/C YES AIR BARRIER N/C N/C YES N/A - NOT APPLICABLE N/C - NO CHANGE N/R - NOT REQUIRED N/P - NOT PROVIDED TO THE BEST OF THE REGISTERED DESIGN PROFESSIONALS KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGEMENT, THESE PLANS AND/OR SPECIFICATIONS ARE IN COMPLIANCE WITH THE 2020 ENERGY CONSERVATION CONSTRUCTION CODE OF NEW YORK STATE. SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 8/ 7 / 2 0 2 3 9 : 4 0 : 4 6 A M Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED CODE DATA, WIND UPLIFT DESIGN CRITERIA, AND GENERAL NOTES G-101 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 312 BID DOCUMENTS PLUMBING CODE SUMMARY DATA ITEM (SECTION)PROPOSED REMARKS TOWN OFFICES, COURT CLERK, BASEMENT EMPLOYEE LOUNGE & 2ND FLOOR (B) COURTROOM & LOBBY (A) STORAGE (S-1) 10681 SF/150=71.2= 72 OCC 2984 SF/15=198.9= 199 OCC 13251 SF/300=44.17= 45 OCC CLASSIFICATION WATER CLOSETS LAVATORIES ASSEMBLY PUBLIC FEMALE (100) MALE (100) 100 OCC/65=1.5 100 OCC/125=0.8 100 OCC/200=0.5 100 OCC/200=0.5 WC<6; UNISEX NOT REQ. BUSINESS EMPLOYEE FEMALE (36) MALE (36) 36 OCC/25=1.44 36 OCC/25=1.44 36 OCC/40=0.9 36 OCC/40=0.9 STORAGE EMPLOYEE FEMALE (23) MALE (23) 23 OCC/100=0.23 23 OCC/100=0.23 23 OCC/100=0.23 23 OCC/100=0.23 TOTAL F: 3.17= 4 WC (2 PUBLIC AND 2 EMP) M:2.47= 3 WC (1 PUBLIC, 2 EMPLOYEE) F: 1.63= 2 LAV M: 1.63= 2 LAV U: 5 WC/5 LAV [1 PUB; 4 EMP.] F: 2 WC/1 LAV [PUB.] M: 2 WC/ 1 LAV. [PUB.] ADDITIONAL ABANDONED FIXTURES IN BASEMENT N/A - NOT APPLICABLE N/C - NO CHANGE N/R - NOT REQUIRED N/P - NOT PROVIDED TO THE BEST OF THE REGISTERED DESIGN PROFESSIONALS KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGEMENT, THESE PLANS AND/OR SPECIFICATIONS ARE IN COMPLIANCE WITH THE 2020 UNIFORM CODE NYS COURT FACILITIES - PART 34 SUMMARY SECTION GUIDELINE PROPOSED REMARKS VI: DESIGN GUIDELINES FOR SECURITY VI: DOORS AND WINDOWS THE DESIGN OF WINDOWS AND DOORS SHOULD DETER ACCESS WITHOUT COMPROMISING AESTHETIC, NATURAL LIGHT AND VIEW CONSIDERATIONS. THE USE OF BETTER COMPONENTS AT SOMEWHAT HIGHER INITIAL COST SHOULD BE CONSIDERED IN ORDER TO PROVIDE BETTER SECURITY THAN AFFORDED BY TRADITIONAL WINDOWS, DOORS, LOCKS & KEYS. THE USE OF IMPACT-RESISTANT GLASS OR PLASTIC MATERIAL SHOULD BE CONSIDERED IN STRATEGIC LOCATIONS. EXTERIOR WINDOWS: IMPACT RESISTANT GLAZING. INTERIOR TRANSACTION AREA: LEVEL 3 BALLISTIC RATING IX: JUDGE'S FACILITIES IX 1: JUDGE'S CHAMBERS The Judge's chambers should have: - a private office (200 sf) - a private restroom or access to a private judges' restroom - space in the office - Immediate access to the secretary and any law clerk - privacy both as to sound and vision - RETAIN 2 JUDGE'S OFFICES (APPROX. 110 SF) - REMOVE EXISTING PRIVATE RESTROOM PER OWNERS REQUEST JUDGE TO HAVE ACCESS TO EMPLOYEE ONLY RESTROOM IX 3: LAW CLER'S OFFICE (150 SF MINIMUM) THE JUDGE'S LAW CLERK SHOULD HAVE A PRIVATE OFFICE TIHW WORK AREA AND SHELVING FOR A WORKING LAW LIBRARY. THE LAW CLERK SHOULD HAVE EASY ACCESS TO THE JUDGE. - SPACE GAINED FROM RESTROOM REMOVAL ADDED TO CLERK OFFICE (APPROX. 56 SF) XI: CLERICAL FACILITIES XI 1: CLERK'S OFFICE THE CLERK'S OFFICE SHOULD INCLUDE: A PUBLIC AREA FOR WAITING/RECEPTION (20 SF/PER; 100 SF MIN) - A PUBLIC COUNTER - A CASHIER'S STATION WITH ADEQUATE SECURITY - A TABLE FOR PUBLIC USE - SEATS FOR WAITING - COIN-OPERATED COPYING MACHINE FOR PUBLIC USE - DISPLAY BOARDS - PUBLIC RECORDS ACCESS AREA GENERAL OFFICE AREA BEHIND COUNTER WITH NO PUBLIC ACCESS - WORKING DESKS (85-95 SF/EMPLOYEE) - RECORD FILES FOR CURRENT WORK - ELECTRONIC DATA PROCESSING EQUIPMENT, IF NECESSARY PRIVATE AREAS - OFFICES FOR CHIEF CLERK AND ASSISTANTS - CONFERENCE ROOM (20 SF/PER) - RECORDS STORAGE AREA - MAIL, SUPPLY , PHOTOCOPYING AND GENERAL SUPPLIES AREA - VAULT OR SAFE FOR STORAGE OF CASH, IMPORTANT RECORDS OR EVIDENCE STAFF FACILITIES AS REQ. BY LAW PER XI.2 TABLE 5 N/C WALL RELOCATED 140 SF/EMPLOYEE N/C N/C XIV: FACILITIES FOR THE PUBLIC XIV.2: PUBLIC RESTROOMS MALE/FEMALE AS PER BUILDING CODE RESTROOMS FOR PUBLIC USE SHOULD BE LOCATED CLOSE TO PUBLIC WAITING AREAS AND CLEARLY MARKED N/C ADDITIONAL SUPPORT STAFF NOT AFFECTED BY SCOPE OF WORK ITHACA ENERGY CODE SUPPLEMENT COMPLIANCE DATA The requirements of this Ithaca Energy Code Supplement shall apply to the following construction: 1) All new construction, excluding additions and renovations that are not specified in this list 2) All additions 500 square feet or larger to single family dwellings or two-family dwellings 3) All additions 1,000 square feet or larger to buildings other than single family dwellings or two- family dwellings 4) All MAJOR RENOVATIONS, as defined below: Any construction or renovation to an existing structure other than a repair or addition, where (A) the WORK AREA exceeds 75 percent of the FLOOR AREA and (B) two or more of the following occur: i) Replacement or new installation of a heating plant or system (e.g. boiler, furnace, or other major system). Changes to ventilation and air conditioning systems are not considered renovations of the heating system. ii) Construction that involves disassembly of greater than 50% of the area of the above-grade portion(s) of the BUILDING THERMAL ENVELOPE in the building. iii) Changes to lighting, including but not limited to new installation, replacement, relocation, or removal, of lamps, lighting, or other illumination fixtures in greater than 50% of the building FLOOR AREA. Space within a building interior that is not currently lit, and is not proposed to be lit, shall not count toward the 50% calculation 1) N/A 2) N/A 3) N/A 4A) <75% 4Bi) N/A 4Bii) <50% 4Biii) <50% N/A - NOT APPLICABLE N/C - NO CHANGE N/R - NOT REQUIRED N/P - NOT PROVIDED TO THE BEST OF THE REGISTERED DESIGN PROFESSIONALS KNOWLEDGE, BELIEF AND PROFESSIONAL JUDGEMENT, THESE PLANS AND/OR SPECIFICATIONS ARE IN COMPLIANCE WITH THE 2020 ENERGY CONSERVATION CONSTRUCTION CODE OF NEW YORK STATE. SCALE:1/8" = 1'-0"2 FIRST FLOOR EGRESS PLAN SCALE:1/8" = 1'-0"1 2ND FLOOR EGRESS PLAN 90' EXIT 113' PER THE THRESHOLDS, THE IEC SUPPLEMENT IN NOT REQIRED R-8.4 AND R-14.7 REGISTRATION EXPIRES: 08/31/2028 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE GENERAL NOTES: 1.ALL SURFACES BEHIND ANY FURRED WALLS ARE ASSUMED TO BE LBP 2.REFER TO DEMO ELEVATIONS FOR EXTENT OF SCOPE 3.WINDOW PAINT ASSUMED TO BE LBP ACM WINDOW GLAZING M02A RESTROOM M01 CORRIDOR M03 TENATE SPACE 2 M02 TENANT SPACE 1 ACM VCT, TO REMAIN. TO BE ENCAPSULATED BY CARPET ACM WINDOW GLAZING GENERAL NOTES: 1.ALL STRUCTURAL STEEL IN THE 2ND FLOOR & ATTIC HAS LEAD-BASED PAINT 2.ALL CEILINGS OF 2ND FLOOR HAVE LEAD-BASED PAINT 3.SCRAPE AND PREP ALL SURFACES ON THE 2ND FLOOR, WOOD TRIM, DOORS, CASING ARE ASSUMED TO BE LBP. TYP. 4.REFER TO DEMO ELEVATIONS FOR EXTENT OF SCOPE 5.WINDOWS PAINT ASSUMED TO BE LBP EXISTING MECHANICAL. SEE M-SERIES DWG. REMOVE ASSUMED ACM INSULATION AND TWO SAWN ABANDONED PIPES. STRIP PAINT FROM HANDRAIL MOUNTING BRACKETS. THIS GROUP OF PIPES TO REMAIN STRIP PAINT FROM ALL DOOR HINGES AND HARDWARE., TYP. REMOVE SHELVING REQIURED TO ACCESS PIPE SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 5 : 2 1 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED HAZARDOUS MATERIALS - ABATEMENT H-101 10/24/2025 HHV,DE DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 313 BID DOCUMENTS SCALE:1/4" = 1'-0"2 HAZARDOUS MATERIAL REMOVALS - FIRST FLOOR SCALE:1/4" = 1'-0"1 HAZARDOUS MATERIALS REMOVALS - 2ND FLOOR SCALE:1/32" = 1'-0"3 KEY PLAN HAZARDOUS MATERIAL ABATEMENT NOTES: GENERAL 1.THE DRAWINGS ARE A GRAPHIC REPRESENTATION OF AREAS THAT HAZARDOUS MATERIALS ARE TO BE ABATED. THE LOCATIONS AND APPROXIMATE QUANTITIES ARE BASED ON VISUAL OBSERVATIONS, SAMPLING AND TESTING. TESTING REPORTS CAN BE FOUND IN THE PROJECT MANUAL. 2.ABATEMENT OF AREAS/MATERIALS SHOWN ARE IDENTIFIED IN THE LEGEND. 3.LOCATIONS AND QUANTITIES INDICATED ON THE CONTRACT DOCUMENTS TAKE PRECEDENCE OVER THE QUANTITIES INDICATED IN THE REPORTS FOUND IN THE PROJECT MANUAL. 4.IF ADDITIONAL SUSPECT MATERIALS ARE DISCOVERED AND/OR DISTURBED, NOTIFY THE ARCHITECT SITE REPRESENTATIVE IMMEDIATELY. THE ON-SITE PROJECT MONITORING FIRM WILL BE RESPONSIBLE FOR SAMPLING. 5.CONTRACTOR SHALL RESTORE/REPAIR AND/OR REPLACE ANY DAMAGE TO ANY AREA OR BUILDING FINISHES AS A RESULT OF TEMPORARY PROTECTION REQUIRED FOR ABATEMENT. 6.THE OWNER SHALL PROCURE A NYSDOL CERTIFIED PROJECT MONITOR WHO WILL HAVE THE AUTHORITY TO HALT THE WORK IF SUCH WORK IS NOT BEING CONDUCTED IN ACCORDANCE WITH THE CONTRACT DOCUMENTS/VARIANCES OR LOCAL, STATE, FEDERAL, RULES, REGULATIONS OR GUIDELINES. 7.COORDINATE THE LOCATION OF ANY REMOTE PERSONNEL AND/OR DECONTAMINATION UNIT, SITE STORAGE OF MATERIAL, EQUIPMENT, WASTE TRAILER/DUMPSTER WITH THE OWNERS SITE REPRESENTATIVE. 8.ALL ON-SITE HAZARDOUS MATERIALS ARE TO BE STORED IN A LOCKABLE CONTAINER. ALL REGULATED HAZMAT MATERIAL IS TO HAVE A MANIFEST SIGNED BY THE OWNER'S REPRESENTATIVE PRIOR TO LEAVING THE SITE. A COPY OF THE PROCESSED MANIFEST MUST BE RETURNED TO THE OWNER AND PROJECT MONITOR WITHIN THIRTY (30) DAYS. 9.WORK SHALL BE CONDUCTED IN CONFORMANCE WITH THE FOLLOWING CODES AND REGULATIONS: 1.A.PART 56 OF TITLE 12 OF THE OFFICIAL COMPILATION OF CODES, RULE AND REGULATIONS OF THE STATE OF NEW YORK (CITED AS 12 NYCRR PART 56) 1.B.CODE OF FEDERAL REGULATIONS 29 CFR 1926.1101 CONSTRUCTION STANDARD FOR ASBESTOS - OSHA 1.C.CODE OF FEDERAL REGULATIONS 29 CFR 1926.59 & 1910.1200 HAZARD COMMUNICATION STANDARD - OSHA 1.D.CODE OF FEDERAL REGULATIONS 40 CFR 763 SUBPART F - EPA AHERA 1.E.CODE OF FEDERAL REGULATIONS 49 CFR SUBPART M NATIONAL EMISSION STANDARD FOR ASBESTOS - NESHAPS HAZARDOUS MATERIAL ABATEMENT NOTES: EXTERIOR SEALANTS 1.THE ABATEMENT CONTRACTOR SHALL BE RESPONSIBLE TO ENSURE THE PERIMETER GROUND IS FREE OF ALL CAULKING AND GLAZING DEBRIS AT THE END OF ABATEMENT. 2.ENSURE THAT ALL SEALANT IS REMOVED FROM MASONRY MATERIAL (BRICK, STONE, CONCRETE BLOCK, PRECAST) AND FRAMES. 3.REMOVE EXTERIOR AND INTERIOR SEALANTS OF OPENING. 4.PROPERLY PROTECT THE ENCLOSURE ASSEMBLY FROM WEATHER, AND ENTRY. 5.PCB-CONTAINING ABATED SEALANT IS TO HAVE A DISTINCT WASTE STREAM PATH FROM ASBESTOS CONTAINING SEALANT. 6.MASONRY MATERIALS TO REMAIN THAT HAVE HAD PCB CONTAINING SEALANTS ABATED ARE TO RECEIVE A PRIME COAT OF EPOXY PAINT TO PREVENT MIGRATION OF PCB'S BACK INTO NEW SEALANT JOINT. SEE PAINTING SPECIFICATION 09 90 00. ASBESTOS ABATEMENT NOTES: INTERIOR 1.ADDITIONAL ACM, LBP, AND/OR PCB MATERIALS MAY BE PRESENT IN WALL, CEILING AND FLOOR CAVITIES THAT WHERE NOT ACCESSIBLE DURING SAMPLING. 2.CONTAINMENT AND WORK AREA LOCATIONS ARE TO BE SELECTED AND SIZED BY THE CONTRACTOR AND SHALL BE SEQUENCED IN ALIGNMENT WITH THE PROJECT PHASING REQUIREMENTS. 3.COORDINATE WITH ALL TRADES REGARDING ELECTRICAL, HVAC, AND PLUMBING SHUTDOWNS/LOCK-OUTS NEEDED TO CONDUCT ABATEMENT. 4.ALL DEMOLITION NECESSARY TO ACCESS HAZARDOUS MATERIALS FOR REMOVAL MUST BE CONDUCTED WITHIN A NEGATIVE PRESSURE ENCLOSURE. DEMOLITION DEBRIS MAY BE DISPOSED OF AS CONDUCTION DEBRIS PROVIDED THE PROJECT MONITOR DETERMINES THAT IT IS NOT CONTAMINATED AND THERE HAS BEEN NO DISTURBANCE WITH THE ENCLOSURE. IF THE DEMOLITION DEBRIS IS DETERMINED TO BE CONTAMINATED OR ACM WITHIN THE ENCLOSURE HAS BEEN DISTURBED, IT MUST BE DISPOSED OF AS ASBESTOS WASTE. 5.ATTACHED ITEMS THAT PENETRATE ACM MATERIALS ARE TO BE REMOVED UNDER CONTAINMENT. LEAD NOTES: 1.ASSUME LEAD-BASED PAINT (LBP) EXISTS THROUGHOUT THE FACILITY. IMPLEMENT LEAD-SAFE PRACTICES IN COMPLIANCE WITH ALL LOCAL, STATE, FEDERAL REGULATIONS AND RECOMMENDATIONS. LEGEND: ACM = ASBESTOS CONTAINING MATERIAL VAT = VINYL ASBESTOS FLOOR TILE PCB = POLYCHLORINATED BIPHENYLS LBP = LEAD BASED PAINT LF = LINEAL FEET SF = SQUARE FEET REGISTRATION EXPIRES: 08/31/2028 ROOM FINISH SCHEDULE SPACE FLOOR BASE CEILING GENERAL REMARKSROOMDOOR MARK MATERIAL FINISH COLOR MATERIAL FINISH COLOR MATERIAL FINISH COLOR MATERIAL HEIGHT FINISH COLOR 102 EXIST.--EXIST./TILE -EXISTING P-1 P-1 ALIGN NEW PARTITION WITH EXIST. PROVIDE SMOOTH TRANSITION 103 -EXIST/TILE -EXIST./TILE -EXIST. GWB/FRP PAINT P-1/FRP-1 EXIST./GWB ±9'-0"/12'-0"PAINT - 104 104-1 EXIST./TILE -EXIST./TILE -PAINT P-1/FRP-1 EXIST./GWB REINSTALL EXISTING DOOR 105 105-1 CARPET -C1 VINYL -V1 EXISTING GWB - 107 107-1 CARPET --- 108 ---- 109 ---- 110 ---- 3 3-1 --- M01 ---P-3 - M02 MO2-1 -- MO2A MO2A-1 --- MO3 --- - ±9'-0"/12'-0"PAINT NORTH MATERIAL FINISH COLOR SOUTH WALLS MATERIAL FINISH COLOR EAST MATERIAL FINISH COLOR WEST PAINT EXISTING/GWB EXISTING/GWB EXISTINGPAINTPAINT EXISTING/FRP PAINT EXISTING/FRP PAINT GWB/FRP PAINT PAINT GWB/FRP PAINT EXIST. GWB/FRP PAINT GWB/FRP-1 PAINT EXIST./ GWB EXISTINGPAINTP-1 PAINT PAINT PAINT EXIST./GWB GWB EXISTING EXISTINGPAINTP-1 PAINT PAINT PAINT EXISTING EXISTING EXISTING EXISTINGPAINTP-1 PAINT PAINT PAINTCARPET EXISTING GWB EXISTING EXISTINGPAINTP-1 PAINT PAINT PAINT EXISTING GWB EXISTING EXISTINGPAINTP-1 PAINT PAINT PAINT EXISTING EXISTING EXISTING EXISTINGPAINTP-1 PAINT PAINT PAINT CARPET CARPET CARPET CARPET CARPET EXISTING EXISTING CLEAN TREADS EXISTING EXISTING EXISTING/GWB GWB EXIST./GWB GWB PAINT P-2 PAINT PAINT PAINT PAINT P-2 PAINT PAINT PAINT VINYL VINYL VINYL VINYL CLEAN AND POLISH EXISTING TERRAZZO AND MARBLE FLOOR.EXIST./TILE EXIST./TILE EXIST./TILE EXIST./TILEP-2/T-1PAINT PAINT PAINT PAINT EXISTING GWB EXIST./GWB EXISTINGPAINTP-2PAINT PAINT PAINT EXIST./WOOD EXIST./WOOD TILE EXIST./WOOD MATCH EXIST. T-3 EXIST./GWB ±8'-8" EXIST./GWB PAINT C1 C1 C1 C1 C2 C2 C2 V1 V1 V1 V1 EXIST./GWB PAINT EXIST./GWB PAINT EXIST./ACT EXIST./ACT EXISTING PAINT EXISTING EXISTING EXISTING PAINT EXISTING PAINT EXISTING PAINT ±9'-0"/12'-0" ±9'-0"/12'-0" ±9'-0"/12'-0" ±9'-0"/12'-0" ±9'-0"/12'-0" ±8'-0" ±8'-0" ±8'-0" ±9'-0" ±8'-0"EXISTING P-3 T-1 P-3 P-1 P-1/FRP-1 P-1/FRP-1 P-1 P-1 P-1 P-1 P-1 P-1 P-2 P-2 P-2/T-1 P-2 P-1 P-1/FRP-1 P-1/FRP-1 P-1 P-1 P-1 P-1 P-1 P-1 P-2 P-2 P-2/T-1 P-2 P-1 P-1/FRP-1 P-1/FRP-1 P-1 P-1 P-1 P-1 P-1 P-1 P-2 P-2 P-2/T-1 P-2 P-1 P-1 P-1 P-1 P-1 ACT-1 ACT-1 P-1 P-5 P-5 P-5 PAINT P-5 T-3 T-3 T-3 EXIST. GWB/FRP WINDOW TRIM P-1 P-1 P-1 P-1 P-1 P-1 P-1 P-1 P-4 P-3 P-3 P-3 P-3 PAINT 4 1 4" PLAN SECTION ℄℄1'-4" REUSE 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. 5 8" TYPE X GWB MINERAL WOOL INSULATION VAPOR RETARDER SECTION 41 4" PLAN SECTION ℄℄1'-4" 02 0604 ±6 3 4" V . I . F . PLAN SECTION ℄℄1'-4" 05 2 5 / 8 " PLAN SECTION 2" HAT CHANNEL 5 8" TYPE X GWB, PAINT INSULATION VAPOR RETARDER 01 4 1 4" PLAN SECTION ℄℄1'-4" 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. 5 8" TYPE X GWB MINERAL WOOL INSULATION VAPOR RETARDER 03 EXISTING MASONRY WALL 47 8" ℄℄1'-4" 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. MINERAL WOOL INSULATION ALIGN WITH EXISTING WALL FOR A SMOOTH TRANSITION ±7 " V . I . F . ±7 " V . I . F . PLAN SECTION 07 47 8" ℄℄1'-4" 5 1 2" LIGHT GAUGE METAL FRAMING 16" O.C. 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. MINERAL WOOL INSULATION 3 5 8 SHAFT WALL FRAMING 16" O.C. MINERAL WOOL INSULATION MINERAL WOOL INSULATION 5 8" TYPE X GWB, PAINT SECTION 08 PLAN EXISTING MASONRY WALL 5 8" TYPE X GWB, PAINT 1/2" FIBERGLASS BALLISTIC MATERIAL CARRY TO CEILING PLAN EXISTING MASONRY WALL EXISTING MASONRY WALL R-8.5 R-14.7 R-14.7 EXISTING WALL 1/2" FIBERGLASS BALLISTIC MATERIAL CARRY TO CEILING VINYL BASE 5 8" TYPE X GWB MINERAL WOOL INSULATION VAPOR RETARDER EXISTING MASONRY WALL REUSE 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. TILE BASE MATCH EXISTING SEAL VAPOR RETARDER TO FLOOR 3 5 8 SHAFT WALL FRAMING 16" O.C. 5 8" TYPE X GWB MINERAL WOOL INSULATION 5 8" TYPE X GWB VAPOR RETARDER EXISTING MASONRY WALL TILE BASE MATCH EXISTING SEAL VAPOR RETARDER TO FLOOR 2" HAT CHANNEL MINERAL WOOL INSULATION 5 8" TYPE X GWB MINERAL WOOL INSULATION VAPOR RETARDER EXISTING MASONRY WALL 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. SEAL VAPOR RETARDER TO FLOOR 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. 5 8" TYPE X GWB, PAINT TILE BASE WOOD BASE MATCH EXISTING, PAINTBASE VARIES SEE SCHED. WOOD BASE MATCH EXISTING, PAINT 5 12" LIGHT GAUGE METAL FRAMING 16" O.C. MINERAL WOOL INSULATION TILE WAINSCOT MINERAL WOOL INSULATION 5 8" TYPE X GWB, PAINT 5 8" TYPE X GWB, PAINT 3 5 8 LIGHT GAUGE METAL FRAMING 16" O.C. 5 8" TYPE X GWB, PAINT VINYL BASE MINERAL WOOL INSULATION 1/2" FIBERGLASS BALLISTIC MATERIAL CARRY TO CEILING URINAL WATER CLOSET (UR.) (W.C.)LAVATORY (LAV.) CLOSET (W.C.) 1'-6" 1' - 5 " 3'-0" 1'-0" 8" 1' - 6 " 1'-0"3'-6" 3' - 3 " 3'-4" 1' - 5 " 2' - 1 0 " 3' - 0 " 3' - 0 " GRAB BAR (G.B.) PAPER TOWEL (PTD) MIRROR (T . T . D . ) SOAP DISPENSER TO I L E T T I S S U E D I S P E N S E R (SD.) 44 " - 4 8 " 3' - 4 " OV E R C O U N T E R O R L A V . 35 " M A X I F N O T O V E R CO U N T E R O R L A V 44 " - 4 8 " 2' - 0 " CE N T E R O F V A L V E DISPENSER WATER TI L E O R F R P W A I N S C O T 4' - 0 " M I N . DOOR SCHEDULE MARK FRAME DOOR FRAME FINISH DOOR UNDERCUT DOOR/ TRIM FINISH HARDWARE GENERAL REMARKSWIDTHHEIGHTMATERIALTYPEWIDTHHEIGHTTHICKNESSMATERIALTYPESET NO.KEYSIDE ROOM NO. 104-1 EXISTING EXISTINGPAINT, P-4 -PAINT, P-4 EXIST.102 REINSTALL SALVAGED DOOR, PATCH AND REPAIR HM FRAME, PAINT 105-1 3'-4"7'-2"HM 1 3'-0"7'-0"1 3 4"WOOD A -CLEAR FINISH (D)/PAINT, P-4 (T) 1 107-1 3'-0"7'-0"HM BPAINT, P-4 -PAINT, P-4 102 C PAINT, P-4 M02-1 2'-6"7'-0" - HM 2" UNDERCUTM02A-1 EXISTING EXISTING REINSTALL SALVAGED DOOR. MATCH TRIM IN KIND EXISTING EXISTING EXISTING 3'-4"7'-2"HM 1 BULLET RESISTANT LEVEL 3 RATED. FOB PROVIDED AND INSTALLED BY OWNER. ELECTRIC STRIKE BY OTHERS, ELECTRICIAN TO INSTALL 22-6 AND 18-4 STANDARD WIRE FROM IT ROOM TO STRIKE PLATE. ADA OPENER SEE E SERIES HM 12'-10"7'-2" EXISTINGEXISTINGEXISTINGEXISTING ±2'-8" V.I.F.EXISTING EXISTING EXISTING±6'-10" V.I.F. HEAD JAMB 2/A-701 6/A-701 3/A-701 7/A-701 M02-2 M03-1 2" UNDERCUTEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTING 1 3 4" LOUVERED BASE 3-1 2" UNDERCUTEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTING ELECTRIC STRIKE BY OTHERS, ELECTRICIAN TO INSTALL 22-6 AND 18-4 STANDARD WIRE FROM IT ROOM TO STRIKE PLATE. 1 3 4" 105 EXISTINGWOOD 2 3 4 5 7 6 FOB PROVIDED AND INSTALLED BY OWNER. ELECTRIC STRIKE BY OTHERS, ELECTRICIAN TO INSTALL 22-6 AND 18-4 STANDARD WIRE FROM IT ROOM TO STRIKE PLATE 3'-4"7'-2"3'-0"7'-0"1 3 4"WOOD APAINT, P-4 M01 M02 M01 M01 101 EXISTINGEXISTING PAINT, P-3 PAINT, P-3 PAINT, P-3 PAINT, P-3 PAINT, P-3 PAINT, P-3 PAINT, P-3 PAINT, P-4 - 4/A-701 8/A-701 5/A-701 9/A-701 CLEAR FINISH (D)/PAINT, P-4 (T) 103-1 EXISTING EXISTINGPAINT, P-4 PAINT, P-4 EXIST.102EXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTING REINSTALL SALVAGED DOOR, PATCH AND REPAIR HM FRAME, PAINT M01-1 -EXISTING EXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTINGEXISTING EXIST.M01PAINT, P-3PAINT, P-3 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 5 : 4 1 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 WALL TYPES AND SCHEDULES A-001 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 314 BID DOCUMENTS SCALE:1" = 1'-0"1 WALL TYPES SCALE:1/2" = 1'-0"3 ADA MOUNTING HEIGHTS SCALE:N.T.S.2 ROOM FINISH SCHEDULE AND DOOR SCHEDULE A/C AIR CONDITIONER A.F.F ABOVE FINISHED FLOOR A.F.G.ABOVE FINISHED GRADE AG.ABOVE GRADE ALT.ALTERNATE ALUM.ALUMINUM ANOD.ANODIZED ASPH.ASPHALT BLKG.BLOCKING CCSF CLOSED-CELL SPRAY FOAM CJ CONTROL JOINT CONC.CONCRETE CONST.CONSTRUCTION CONT.CONTINUOUS DIA.DIAMETER DIM.DIMENSION DIMS.DIMENSIONS DWG.DRAWING EA.EACH EF EXHAUST FAN EJ EXPANSION JOINT ELEC.ELECTRICAL EX. or EXIST.EXISTING EXJT.EXPANSION JOINT FIN.FINISH FLR.FLOOR GA.GAUGE GALV.GALVANIZED GYP.GYPSUM HVAC HEATING, VENTILATION AND AIR CONDITIONING INC.INCLUDING INSUL.INSULATED or INSULATION LGMF LIGHT GAUGE METAL FRAMING MANUF.MANUFACTURER MAX.MAXIMUM MECH.MECHANICAL MEMB.MEMBRANE MIN.MINIMUM MTL.METAL N.I.C.NOT-IN-CONTRACT N.T.S.NOT TO SCALE OZ. OUNCE PLUMB.PLUMBING PLYD.PLYWOOD PNT.PAINT or PAINTED PP PIPE PENETRATION PRE POWER ROOF EXHAUST P.S.F.POUNDS PER SQUARE FOOT P.S.I.POUNDS PER SQUARE INCH PT PRESSURE TREATED PVC POLYVINYL CHLORIDE REINF.REINFORCED SF SQUARE FOOT SIM. SIMILAR S.S.STAINLESS-STEEL STL.STEEL STRUCT.STRUCTURE or STRUCTURAL T&G TONGUE AND GROOVE TYP.TYPICAL V.I.F.VERIFY IN FIELD V.R.VAPOR RETARDER W/WITH WD.WOOD TYPICAL ABBREVIATIONS: REGISTRATION EXPIRES: 08/31/2028 M02A RESTROOM M01 CORRIDOR AD-201 1 4 3 2 AD-201 9 12 11 10 AD-201 5 8 7 6 M03 TENATE SPACE 2 M02 TENANT SPACE 1 3'-0"± REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATIONREMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION REMOVE DOOR, FRAME, HARDWARE AND MARBLE THRESHOLD. SALVAGE FOR REINSTALLATION REMOVE WOODEN SHELVING IN ITS ENTIRETY REMOVE WINDOW TRIM, TYP. REMOVE SECTION OF PLASTER PARTITION AND BACKUP FOR NEW DOOR REMOVE WOOD PANEL AND WINDOW TRIM REMOVE WINDOW TRIM REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. REMOVE WINDOW TRIM, TYP. NOTE: CONTRACTOR TO SECURE OPENINGS AND MAKE WEATHER TIGHT WHILE WINDOWS ARE REMOVED., TYP. EXISTING TERRAZZO AND MARBLE FLOOR TO REMAIN EXISTING DUCT TO REMAIN EXISTING DUCT TO REMAIN. SAND HANDRAIL,PREPARE FOR NEW FINISH REMOVE MARBLE WAINSCOT IN ITS ENTIRETY. RETURN TO OWNER. PREPARE SURFACE FOR NEW FINISHES PIPE TO REMAIN RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR, TYP. RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR, TYP. REMOVE VENTS AND PATCH PLUMBING CONTRACTOR TO REMOVE TOILET AND SINK. GC TO PATCH AND FINISH, TYP. 6'-012" 6' - 2 " 12 ' - 0 1 2" 5' - 1 1 2" REMOVALS AD-101 3 TYP. #PHOTO LOCATION 4 1 3 2, 2A 30'-3" 19 ' - 5 " 15'-11" 5 10" REMOVE METAL STUD PARTITIONS,DOOR, DOOR FRAME AND HARDWARE REMOVE TRANSACTION WINDOW AND SHELF REMOVE DOOR AND FRAME REMOVE WALL TO THE EXTENT SHOWN REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. REMOVE ALL WINDOW TRIM, TYP. RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR, TYP. REMOVE CARPET AND PAD. REMOVE WALL TO THE EXTENT SHOWN 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE NOTE: REPLACE FLOOR TILE. PATCH AND REPAIR FLOOR AREAS DAMAGED BY REMOVALS IN RESTROOMS 103 AND 104 PREPARE SURFACE FOR NEW FINISH. ± 60 S.F V.I.F. TOTAL REMOVE LIGHT REMOVE WINDOW AND TRIM TOILETS AND GRAB BARS TO BE REMOVED BY PLUMBING CONTRACTOR. SAVE FOR REINSTALLATION. REMOVE AND SALVAGE DOOR AND FRAME. PROVIDE MIN. OF 3'-4" OPENING FOR NEW ADA DOOR. DO NOT DISTURB MARBLE REMOVE MIRROR AND GRAB BARSREMOVE AND SALVAGE MIRROR AND SOAP DISPENSER REMOVE SINK, MIRROR, SOAP DISPENSER AND PAPER TOWEL. SAVE FOR REINSTALLATION REMOVE TOILET PARTITIONS IN ITS ENTIRETY RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR REMOVE VCT DOWN TO SUBSTRATE REMOVE WINDOW TRIM, TYP. REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. REMOVE PLASTER BACK TO EXISTING MASONRY WALL ±8'-212" NOTES: 1.ALL INTERIOR PARTITIONS THAT INTERSECT EXTERIORS WALLS SHALL BE OPENED AND INSULATED AT THE INTERSECTION TO A DEPTH EQUAL TO OR GREATER THAN THE PROPOSED EXTERIOR WALL THICKNESS. PATCH AND FINISH AREA. 2.CONTRACTOR TO SECURE OPENINGS AND PROVIDE WEATHER TIGHTNESS REQUIREMENTS WHILE WINDOWS ARE REMOVED. TYPICAL 3.UNLESS SPECIFICALLY INDICATED REMOVALS BY GC 4.PROVIDE ONE OPERATIONAL RESTROOM ACCESSIBLE TO THE PUBLIC AT ALL TIMES. PLUMBING CONTRACTOR TO REMOVE TOILET, SINK 53'-412" 19 ' - 3 1 2" 10 ' - 8 1 2" REMOVALS REMOVE GRAB BARS TOILETS TO BE REMOVED BY PLUMBING CONTRACTOR. SAVE FOR REINSTALLATION. REMOVE TOILET PARTITIONS IN ITS ENTIRETY REMOVE HAT CHANNEL AND GWB ON EXISTING MASONRY WALL RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR, TYP. AD-101 4 TYP. 7 #PHOTO LOCATION 6 3' - 4 " PROVIDE R.O. 3'-4"X 7'-2" FOR DOOR SINK TO BE REMOVED BY PLUMBING CONTRACTOR. SAVE FOR REINSTALLATION EX. DOOR TO REMAIN REMOVE DOOR 91 2" ±1 ' - 2 " REMOVE CHASE WALL REMOVE WINDOW SASH ONLY. WINDOW FRAME TO REMAIN REMOVE WINDOW TRIM. TYPICAL W6 W5 W6 REMOVE WINDOW SASH ONLY. WINDOW FRAME TO REMAIN REMOVE WINDOW TRIM. TYPICAL EXISTING TRIM PANELS TO REMAIN SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 5 : 5 5 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED REMOVALS-FLOOR PLANS AD-101 10/24/2025 SLC - 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 315 BID DOCUMENTS SCALE:1/4" = 1'-0"1 REMOVALS- 2ND FLOOR PLAN SCALE:1/4" = 1'-0"2 REMOVALS-FIRST FLOOR PLAN SCALE:1/32" = 1'-0"5 KEY PLAN SCALE:1/2" = 1'-0"3 2ND FLOOR PARTIAL ELEVATION @ WINDOW SCALE:1/2" = 1'-0"4 FIRST FLOOR PARTIAL ELEVATION @ WINDOW PHOTO 7 TRANSACTION WINDOW PHOTO 1 TRANSACTION WINDOW PHOTO 2 VENT REMOVAL PHOTO 4 ROOM MO2 PHOTO 3 PHOTO 5 ROOM M02A PHOTO 6 CLERK BATHROOM REMOVAL PHOTO 2A VENT REMOVAL REGISTRATION EXPIRES: 08/31/2028 106 RESTROOM 102 CORRIDOR 108 CORRIDOR 110 OFFICE CEILING HGT. 9'-0" CEILING HGT. 9'-0" CEILING HGT. 9'-0" CEILING HGT. 9'-0" CEILING HGT. 9'-0" CEILING HGT. 8'-0" 104 RESTROOM 103 RESTROOM 111 TOWN BOARD/COURTROOM101 LOBBY PROVIDE OPENING IN GWB CEILING IN AREA SHOWN FOR INSTALLATION OF INSULATION ACT CEILING TO REMAIN ACT CEILING TO REMAIN PROVIDE OPENING IN GWB CEILING IN AREA SHOWN FOR LGMF PARTITION AND INSULATION, SEE 2/A-301 SIM. 109 OFFICE REMOVE SOFFIT AND SALVAGE CEILING GRID AND TILE TO THE EXTENT SHOWN FOR LGMF PARTITION AND INSULATION. SEE 1/A-301 AND 3/A-301. ASSUME 3' DEEP PROVIDE OPENING IN GWB CEILING AS REQ'D IN AREA SHOWN FOR LGMF PARTITION AND INSULATION, SEE 2/A-301 SIM. ASSUME 3' DEEP. SPRINKLERS, SMOKE/HEAT AND DIFFUSERS TO REMAIN, TYP. SPRINKLERS, SMOKE/HEAT AND DIFFUSERS TO REMAIN. TYP. SPRINKLERS, SMOKE/HEAT AND DIFFUSERS TO REMAIN. TYP. SPRINKLERS TO REMAIN LIGHT TO BE REMOVED BY ELECTRICAL CONTRACTOR. GENERAL CONTRACTOR TO PATCH HOLES AND FINISH, TYP. 3 1 GENERAL NOTES: 1.LIGHTS TO BE REMOVED BY ELECTRICAL CONTRACTOR. COORDINATE WITH E-SERIES, TYP. 2.GENERAL CONTRACTOR TO PATCH HOLES, ASSUME 50 S.F. PREP EXISTING GWB CEILINGS FOR PAINTING, TYP. EXISTING EXIT SIGN TO REMAIN EXISTING EXIT SIGN TO REMAIN M02A RESTROOM M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR LIGHTS TO BE REMOVED BY ELECTRICAL CONTRACTOR. GENERAL CONTRACTOR TO PATCH HOLES AND FINISH, TYP. EXISTING DUCT EXISTING DUCT EXISTING DUCT EXISTING FIRE SENSOR TO REMAIN LIGHTS TO BE REMOVED BY ELECTRICAL CONTRACTOR. GENERAL CONTRACTOR TO PATCH HOLES AND FINISH, TYP. LIGHT TO BE REMOVED BY ELECTRICAL CONTRACTOR. GENERAL CONTRACTOR TO PATCH HOLES AND FINISH, TYP. 2 GENERAL NOTES: 1.LIGHTS TO BE REMOVED BY ELECTRICAL CONTRACTOR. COORDINATE WITH E-SERIES, TYP. 2.GENERAL CONTRACTOR TO PATCH HOLES, ASSUME 50 S.F. PREP EXISTING GWB CEILINGS FOR PAINTING, TYP. DIFFUSER SUPPLY DIFFUSER RETURN SPRINKLER SMOKE/ HEAT LEGEND EMERGENCY LIGHT LIGHT WALL MOUNTED EXIT LIGHT SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 0 0 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 REMOVALS REFLECTED CEILING PLAN AD-111 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 316 BID DOCUMENTS SCALE:1/32" = 1'-0"3 KEY PLAN SCALE:1/4" = 1'-0"2 REMOVALS FIRST FLOOR REFLECTED CEILING PLAN SCALE:1/4" = 1'-0"1 REMOVALS 2ND FLOOR REFLECTED CEILING PLAN SCALE:N.T.S.-LEGEND PHOTO 1 CEILING OFFICE 110 PHOTO 2 CEILING ROOM MO2 PHOTO 3 CEILING OFFICE 107 REGISTRATION EXPIRES: 08/31/2028 8' - 1 1 " 12'-014"7'-43 4" 8" REMOVE WINDOW TRIM 19'-5" EXISTING METAL PIPE TO REMAIN REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR 4" EXISTING DUCTS TO REMAIN CONDUIT AND JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR 7' - 6 " 1' - 5 " 5'-112"1'-11"2'-33 8"3'-0"2'-612"2'-5"2'-11 2" 6' - 8 " REMOVE DOOR, AND ALL RELATED HARDWARE. SALVAGE FOR REUSE. REFURBISH HARDWAREEXISTING DUCT TO REMAIN REMOVE WOOD TRIM SPRINKLER PIPE TO BE REMOVED BY PLUMBING CONTRACTOR. GC TO PATCH AND FINISH, TYP. 7' - 6 " 1' - 5 " 4" 9'-0" 8' - 1 1 " 16'-23 8"4'-95 8" REMOVE WINDOW TRIM, TYP. 30'-0" REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR CONDUIT AND JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR 3' - 6 " 7' - 6 " 6'-3" REMOVE MARBLE WAINSCOT, AND DOOR TRIM, RETURN MARBLE TO OWNER CONDUIT AND JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR SPRINKLER PIPE TO BE REMOVED BY PLUMBING CONTRACTOR. GC TO PATCH AND FINISH, TYP. 2'-812" 3' - 6 " 7' - 6 " ± 7 ' - 2 " REMOVE SECTION OF PLASTER PARTITION AND BACKUP FOR NEW DOOR REMOVE MARBLE WAINSCOT, RETURN TO OWNER 3'-0"6" 6'-21 2" CONDUIT AND JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR 6'-3" 3' - 6 " 7' - 6 " REMOVE MARBLE WAINSCOT, RETURN TO OWNER RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR SPRINKLER PIPES TO BE REMOVED BY PLUMBING CONTRACTOR. GC TO PATCH AND FINISH, TYP. 6'-212" 3' - 6 " 7' - 6 " REMOVE WOOD PANEL AND TRIM, PREPARE OPENING FOR REPLICA WINDOW REMOVE MARBLE WAINSCOT, RETURN TO OWNER ±3 ' - 3 " V . I . F . ±2'-218" V.I.F. TOILET, SINK AND T.R. ACCESSORIES TO BE REMOVED BY PLUMBING CONTRACTOR CAP BACK TO SOURCE. ALL CONDUIT, LIGHT AND FAN TO BE REMOVED BY ELECTRICAL CONTRACTOR. GENERAL CONTRACTOR TO PATCH AND REPAIR SURFACE FOR NEW PAINT., TYP. SPRINKLER PIPES TO BE REMOVED BY PLUMBING CONTRACTOR. GC TO PATCH AND FINISH, TYP. REMOVE PAPER TOWEL DISPENSER, SOAP DISPENSER AND TOWEL BAR 7'-05 8"3'-0"5'-33 8" 15'-4" 8" 7' - 6 " 6' - 2 " REMOVE WOODEN SHELVING ITS ENTIRETY RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR CONDUIT AND JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR 15'-11" EXISTING DUCTS TO REMAIN REMOVE VENT INFILL, PATCH AND PAINT PIPE TO REMAIN REMOVE WOODEN SHELVING IN ITS ENTIRETY PIPES TO BE REMOVED BY MECHANICAL CONTRACTOR 3'-4"12'-0" 7' - 6 " 15'-4" REMOVE WOODEN SHELVING IN ITS ENTIRETY PLUMBING CONTRACTOR TO ADJUST PIPE ± 6" TO ACCOMMODATE NEW WALL THICKNESS. EXISTING DUCTS TO REMAIN PIPES TO REMAIN 15'-1012" 7' - 6 " 8" REMOVE WOODEN SHELVING IN ITS ENTIRETY REMOVE WINDOW TRIM REMOVE/SALVAGE WINDOW SASH FOR RESTORATION AND REINSTALLATION, TYP. SPRINKLER PIPES TO BE REMOVED BY PLUMBING CONTRACTOR JUNCTION BOX TO BE REMOVED BY ELECTRICAL CONTRACTOR PIPE TO RADIATOR TO BE REMOVED BY MECHANICAL CONTRACTOR SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 0 9 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED REMOVALS-INTERIOR ELEVATIONS AD-201 10/24/2025 SLC DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 317 BID DOCUMENTS SCALE:3/8" = 1'-0"1 REMOVALS - TENANT SPACE 1 M02- WEST ELEVATION SCALE:3/8" = 1'-0"2 REMOVALS - TENANT SPACE 1 MO2- NORTH ELEVATION SCALE:3/8" = 1'-0"3 REMOVALS - TENANT SPACE 1 MO2 - EAST ELEVATION SCALE:3/8" = 1'-0"4 REMOVALS - TENANT SPACE 1 MO2 - SOUTH ELEVATION SCALE:3/8" = 1'-0"5 MO2A-WEST EL. SCALE:3/8" = 1'-0"6 REMOVALS-M02A-NORTH EL. SCALE:3/8" = 1'-0"7 REMOVALS-M02A - EAST EL. SCALE:3/8" = 1'-0"8 REMOVALS - M02A - SOUTH EL. SCALE:3/8" = 1'-0"9 REMOVALS - TENANTE SPACE 2 MO3 - WEST ELEVATION SCALE:3/8" = 1'-0"10 REMOVALS - TENANT SPACE 2 MO3- NORTH ELEVATION SCALE:3/8" = 1'-0"11 REMOVALS - TENANT SPACE 2 MO3- EAST ELEVATION SCALE:3/8" = 1'-0"12 REMOVALS - TENANT SPACE 2 MO3 - SOUTH ELEVATION GENERAL NOTES: 1.PATCH ALL HOLES, ASSUME 10 SF REGISTRATION EXPIRES: 08/31/2028 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 105-1 03 02 03 03 03 03 03 3'-0" 107 OFFICE W11 104 RESTROOM 103 RESTROOM 102 CORRIDOR 2'-7" 2'-6" MIN.5'-0" 01 BULLET-RESISTANT VERTICAL BAFFLE TRANSACTION WINDOW CARPET TILE CARPET TILE PAINT PROVIDE SMOOTH TRANSITION FROM EXISTING WALL, PAINT PAINT CARPET TILE PAINT PAINT 2'-6" 3'-2" 1'-3" 5' - 0 " 5'-0" 06 104-1 10 7 - 1 ±1'-6" REINSTALL WINDOWS, TYP. TRIM, PAINT, TYP. PLUMBING CONTRACTOR TO REINSTALL TOILET. SEE NOTE 1. PLUMBING CONTRACTOR TO INSTALL URINAL. SEE 3/A001. FOR MOUNTING HGTS. REINSTALL GRAB BARS PROVIDE ADDITIONAL BLOCKING AS REQUIRED. SEE 3/A001 FOR MOUNTING HGTS. TOILET PARTITIONS TOILET PARTITIONS PLUMBING CONTRACTOR TO REINSTALL TOILETS. SEE NOTE 1. REPLACE TILE IN AREAS DAMAGED BY REMOVALS IN TOILET ROOMS 103 AND 104. MATCH EXISTING. ± 10 S.F V.I.F. W8 NOTE: CONTRACTOR TO FOAM ALL WEIGHT POCKETS IN WINDOWS FOR AIR TIGHTNESS, TYP. 07 PATCH AND PAINT AREA DISTURBED BY WALL REMOVAL, MATCH EXISTING REINSTALL TOILET ROOM ACCESSORIES. SEE 3/A001 FOR MOUNTING HGTS., TYP. REINSTALL GRAB BARS AND TOILET ROOM ACCESSORIES PROVIDE ADDITIONAL BLOCKING. SEE 3/A001 FOR MOUNTING HGTS. W7 W8W7W8W7 W8W7 A-301 1 A-301 4 A-301 3 A-301 2 A-301 4 A-301 5 A-301 2 A-301 3 SIM. A-301 2 SIM.SIM. 3-1 DO NOT DISTURB MARBLE IN LOBBY CARPET TILE 8'-73 4" PROVIDE WOOD 1 1 4"DIA. HANDRAIL 1' - 1 3 4" 2' - 0 " CABINET NOTE: 1.PLUMBING FIXTURES TO BE INSTALLED BY PLUMBING CONTRACTOR. COORDINATE WITH P-SERIES. 2.GC TO INSTALL ALL NECESSARY BLOCKING. 3.GC TO PERFORM ALL CORING AND DRILLING. COORDINATE LOCATION WITH PLUMBING CONTRACTOR. 4.GC TO PATCH ALL HOLES CREATED BY OTHER TRADES. PREP AND PAINT, TYP. WALL MOUNTED THERMOSTAT AND FIRE ALARM TO REMAIN. ELECTRICAL CONTRACTOR TO MOVE IF THERE IS A CONFLICT PROVIDE 4' WAINSCOT FRP, APPLIED TO ALL WALLS IN ROOM 103 AND ROOM 104, TYP. PROVIDE 4' WAINSCOT FRP, APPLIED TO ALL WALLS IN ROOM 103 AND ROOM 104, TYP. 1'-6" 2' - 4 " 1'-6" ±53 4" 2/A-301 3/A-301 6/A-301 7/A-301 PACK ABUTMENT OF EXISTING PARTITIONS WITH INSULATION FOR CONTINUITY 7' - 1 0 1 4" 3' - 4 " A-501 10 PROVIDE BLOCKING FOR ELECTRIC HEATER. SEE M-SERIES PROVIDE BLOCKING FOR ELECTRIC HEATER. SEE M-SERIES 10 3 - 1 06 1' - 6 " M I N . M03 TENATE SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR 03 03 04 04 04 05 03 03 03 03 PATCH AND PAINT ALL WALLS IN STAIRWELL AND CORRIDOR., TYP. INFILL FORMER DOOR RO WITH FRAMING AND PATCH PLASTER TO MATCH EXISTING PATCH AND PAINT WALLS, TYP. CARPET TILE CARPET TILE CLEAN AND POLISH EXISTING TERRAZZO AND MARBLE FLOOR PLUMBING CONTRACTOR TO INSTALL NEW TOILET AND SALVAGED SINK FROM RM 106. PATCH AND PAINT WALLS AND TRIM 200 SQ.FT. REINSTALL DOOR, PAINT TRIM, MATCH EXISTING. PAINT MO2A-1 PATCH AND PAINT EXISTING WALLS, TYP. GWB, PAINT, TYP. GWB, PAINT, TYP. GWB, PAINT, TYP. A-201 5 8 7 6 A-201 1 4 3 2 A-201 9 12 11 10 M02A RESTROOMW5 REINSTALL WINDOWS, TYP. CONTRACTOR TO FOAM ALL WEIGHT POCKETS IN WINDOWS FOR AIR TIGHTNESS, TYP. REINSTALL WINDOWS, TYP. NOTE: CONTRACTOR TO FOAM ALL WEIGHT POCKETS IN WINDOWS FOR AIR TIGHTNESS, TYP. CARPET TILE WOOD BASE ON ALL NEW WALLS. PAINT, TYP. PAINT WOOD BASE., TYP. PAINT WOOD BASE., TYP. PAINT WOOD BASE., TYP. REFINISH RAILING MO2-2 9'-8" 2' - 1 0 12" 2'-5"2'-012" 1' - 1 1 " 2'-61 2" 2' - 0 12" ±2 ' - 8 " 04 PATCH ABANDONED VENTS W6 W11W5W6 W5 W6 W5 W6 MO2-1 MO3-1 PROVIDE 1 1/4" DIA. WOODEN HANDRAIL 3'-10 12"2'-4" NOTE: 1.PLUMBING FIXTURES TO BE INSTALLED BY PLUMBING CONTRACTOR. COORDINATE WITH P-SERIES. 2.GC TO INSTALL ALL NECESSARY BLOCKING. 3.GC TO PERFORM ALL CORING AND DRILLING. COORDINATE LOCATION WITH MECHANICAL, PLUMBING AND ELECTRICAL CONTRACTOR. 4.GC TO PATCH ALL HOLES CREATED BY OTHER TRADES. PREP FOR PAINTING, TYP. 5.GC TO COORDINATE WITH MECHANICAL , ELECTRICAL, AND PLUMBING CONTRACTOR FOR MOUNTING LOCATIONS. CLEAN STAIR TREADS & RISERS, TYP. PAINT DOOR AND FRAME MO1-1 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 1 9 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED FLOOR PLANS A-101 10/24/2025 SLC - 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 318 BID DOCUMENTS SCALE:1/4" = 1'-0"8 FIRST FLOOR PLAN SCALE:1/4" = 1'-0"3 2ND FLOOR PLAN SCALE:1/32" = 1'-0"6 KEY PLAN REGISTRATION EXPIRES: 08/31/2028 - ATTIC SPACE ± 54'-8" ±8 9 ' - 0 " A-102 1 HIP ROOF ABOVE EXISTING STAIR TO MEZZANINE DN EXISTING CAT WALK EXISTING LOUVER TO REMAIN. N.I.C. EXISTING LOUVER TO REMAIN. N.I.C. SEE NOTE 4B A-600 REMOVE/SALVAGE DORMER WINDOW FOR RESTORATION AND REINSTALLATION REMOVE/SALVAGE DORMER WINDOW FOR RESTORATION AND REINSTALLATION 6" MINERAL WOOL INSULATION WITH SMART VAPOR RETARDER., TYP. AREA OF VAULTED CEILING BELOW REMOVE EXISTING LOOSE INSULATION AS REQUIRED 1 2 34 5 6 SEE NOTE 4A A-600 - ATTIC SPACE 6" MINERAL WOOL INSULATION BETWEEN EXISTING RAFTERS WITH SMART VAPOR RETARDER, TYP. 6" METAL STUD FRAMING WITH 6" MINERAL WOOL INSULATION WITH SMART VAPOR RETARDER DOWN TO VAULTED CEILING BELOW VAULTED CEILING PLUMBING CONTRACTOR TO RELOCATE AND PROTECT ALL SPRINKLER HEADS AS REQ'D AND RETAIN ALL BRANCH PIPING FOR INSTALLATION OF INSULATION. A-701 12 TYPICAL RETURN 6" MINERAL WOOL INSULATION WITH SMART VAPOR RETARDER, TYP. A-102 3 A-102 4 EXISTING PLASTER VAULTED CEILING MINERAL WOOL INSULATION EXISTING MASONRY WALL 6" METAL STUD FRAMING. SPACING TO COINCIDE WITH EXISTING RAFTER SPACING. V.I.F. SMART VAPOR RETARDER. SEAL TO WALL WITH MASTIC FILL VOID WITH INSULATION R-25 EXISTING MASONRY WALL MINERAL WOOL INSULATION. SMART VAPOR RETARDER 6" METAL STUD FRAMING. SPACING TO COINCIDE WITH EXISTING RAFTER SPACING. V.I.F. R-25 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 2 9 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 ATTIC FLOOR PLAN AND SECTION A-102 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 319 BID DOCUMENTS SCALE:1/8" = 1'-0"2 ATTIC PLAN SCALE:1/8" = 1'-0"1 ATTIC SECTION SCALE:1/32" = 1'-0"5 KEY PLAN SCALE:1/2" = 1'-0"3 SECTION ELEVATION SCALE:1/2" = 1'-0"4 PLAN DETAIL NOTE: 1. WEIGHT CANNOT BE APPLIED TO PLASTER CEILING. CONTRACTOR MUST PROVIDE WORK SURFACE OVER STRUCTURE TO SUPPORT INSTALLERS. PHOTO 1 CAT WALK ATTIC PHOTO 2 ATTIC WINDOW (TYPICAL) PHOTO 3 ATTIC DUCT PHOTO 4 VAULTED CEILING FROM ATTIC PHOTO 5 DUCT WORK IN ATTIC FROM CATWALK PHOTO 6 DUCT WORK AND FIREPROTECTION IN ATTIC REGISTRATION EXPIRES: 08/31/2028 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR PAINT PATCH AND PAINT GWB IN THESE AREAS OF WALL AND CEILING REMOVAL PAINT PAINT PAINT PAINT REPAIR OR REPLACE CEILING GRID, TILE AND SOFFIT IN AREAS AFFECTED BY NEW WORK A-301 3 PAINT A-301 4 A-301 4 SIM PAINT A-301 2 PATCH AND PAINT GWB IN THESE AREAS OF WALL AND CEILING REMOVAL. V.I.F. PROVIDE ADDITIONAL CEILING GRID SECTIONS AT FORMER LIGHT LOCATION A-301 1 A-301 2 SIM A-301 3 A-301 2 SIM A-301 5 4'-0" 7' - 2 " 3'-2"6'-11"3'-412" 4' - 3 " EQ.9'-1"EQ. 2' - 1 0 " 8'-6" EQ . EQ . EQ. EQ . EQ . 7' - 0 " EQ. EQ. EQ . EQ . EQ. 6' - 7 12" 3' - 7 12" EQ . EQ . EQ.EQ. M03 TENANT SPACE 2 M02 TENANT SPACE 1 PAINT PAINT PAINT PAINT, TYP. REPAIR HOLES IN CEILING PROVIDE SMOOTH FINISH TO RECEIVE PAINT M02A RESTROOM M01 CORRIDOR 6'-3" 4' - 8 " 8' - 3 " 8'-8"8'-8" EQ. EQ . 1'-4" 7' - 6 " EQ . EQ . EQ.EQ.7'-10"EQ.EQ . DIFFUSER SUPPLY DIFFUSER RETURN SPRINKLER SMOKE/ HEAT LEGEND EMERGENCY LIGHT LIGHT WALL MOUNTED EXIT LIGHT SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 3 4 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 REFLECTED CEILING PLANS A-111 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3110 BID DOCUMENTS SCALE:1/4" = 1'-0"2 FIRST FLOOR REFLECTED CEILING PLAN SCALE:1/4" = 1'-0"1 2ND FLOOR REFLECTED CEILING PLAN SCALE:1/32" = 1'-0"8 KEY PLAN SCALE:N.T.S.9 LEGEND 1.PATCH HOLES FROM LIGHTING FIXTURE REMOVALS AND PREP FOR PAINTING. 2.LIGHTING FIXTURES, EXIT SIGNS, AND SMOKE/HEAT DETECTORS TO BE INSTALLED BY ELECTRICAL CONTRACTOR. COORDINATE WITH E-SERIES, TYP. 3.INFORM ARCHITECT IF LIGHTING FIXTURE LOCATIONS CONFLICT WITH EXISTING SPRINKLERS, DIFFUSERS OR HEAT/SMOKE DETECTORS. GENERAL RCP NOTES: REGISTRATION EXPIRES: 08/31/2028 8' - 1 1 " 19'-03 4" 11'-8"7'-43 4" 8" AD-201PAINT WOOD TRIM, MATCH EXISTING PROFILE, PAINT, TYP. REINSTALL WINDOW SASH, PAINT EX. METAL PIPE, PAINT 19'-03 4" EXISTING WOOD BASE, PAINT, TYP. 4" 2'-5"9'-314"17'-103 4" AD-20129'-3" PAINT GWB, PAINT WOOD BASE MATCH EXISTING, PAINT ± 29'-7" DATA CLOSET DOOR WOOD TRIM, MATCH EXISTING. PAINT EXISTING WOOD BASE. PAINT, TYP. ±4'-95 8" 7' - 6 " 1' - 5 " 4" ±8'-75 8" 8' - 1 1 " ±16'-23 8" PAINT, TYP. EX. PIPE, PAINT WOOD TRIM, MATCH EXISTING PROFILE, PAINT REINSTALL WINDOW SASH, PAINT WOOD TRIM, MATCH EXISTING PROFILE, PAINT REINSTALL WINDOW SASH, PAINT ± 29'-7 3 4" EXISTING WOOD BASE PAINT, TYP. FAN COIL, INSTALLED BY MECHANICAL CONTRACTOR 7' - 6 " 1' - 5 " ± 5'-112"1'-11"3'-93 8"3'-712"1'-414" ±7 ' - 2 " PAINT, TYP. GWB CHASE, PAINT EXISTING BULKHEAD, PAINT ±3'-3" INFILL WALL THIS AREA FROM DOOR REMOVAL. PATCH AND MATCH EXISTING WALL FINISH, PAINT EXISTING WOOD TRIM AND DOOR, PAINT 19'-012" WOOD BASE MATCH EXISTING, PAINT WOOD BASE, MATCH EXISTING, PAINT SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR EXISTING WOOD BASE PAINT. TYP. 7' - 6 " 6'-3" PAINT 3' - 6 " TILE SOAP DISPENSER AND PAPER TOWEL DISPENSER INFILLED AREA FROM DOOR REMOVAL SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR 7' - 6 " PAINT TRIM, MATCH EXISTING, PAINT REINSTALL SALVAGED DOOR AND HARDWARE, PAINT TILE 3' - 6 " WALL MOUNTED HEATER INSTALLED BY MECHANICAL CONTRACTOR. CENTER ON WALL SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR 5'-103 4" 7' - 6 " PAINT PATCH ALL AREAS DAMAGED BY MEP REMOVAL, TYP. TILE 3' - 6 " SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR 6'-212" ±2'-93 4"±3'-43 4" 7' - 6 " WINDOW TRIM, MATCH EXISTING PROFILE, PAINT TILE T1 3' - 6 " MIRROR PATCH WALL IN DAMAGED AREA, PAINT, TYP. SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR 15'-018" 8" 7' - 6 " PAINT EXISTING WOOD DOOR AND TRIM, PAINT, TYP. EXISTING WOOD BASE PAINT, TYP. 15'-63 4" PAINT, TYP. EXISTING WOOD BASE, PAINT, TYP. WOOD BASE MATCH EXISTING. PAINT GWB, PAINT PAINT INFILL AREA FROM VENT REMOVAL 7' - 6 " 14'-113 4" PAINT PIPES, TYP. PAINT GWB, PAINT WOOD BASE, MATCH EXISTING, PAINT PAINT, TYP. 4'-21 4"11'-49 16" 15'-63 4" 7' - 6 " PAINT WOOD TRIM, MATCH EXISTING PROFILE, PAINT REINSTALL WINDOW SASH, PAINT FAN COIL, INSTALLED BY MECHANICAL CONTRACTOR SPRINKLER PIPE TO BE INSTALLED BY PLUMBING CONTRACTOR EXISTING PIPE, PAINT EXISTING WOOD BASE, PAINT SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 6 : 4 4 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Syracuse, NY 13204 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Pittsford, NY 14534 Tel (585) 200 - 5038 1160-C Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED INTERIOR ELEVATIONS A-201 10/24/2025 SLC DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3111 BID DOCUMENTS SCALE:3/8" = 1'-0"1 TENANT SPACE 1 MO2 - WEST ELEVATION SCALE:3/8" = 1'-0"2 TENANT SPACE 1 MO2- NORTH ELEVATION SCALE:3/8" = 1'-0"4 TENANT SPACE 1 MO2- SOUTH ELEVATION SCALE:3/8" = 1'-0"3 TENANT SPACE 1 MO2- EAST ELEVATION SCALE:3/8" = 1'-0"5 MO2A-WEST EL. SCALE:3/8" = 1'-0"6 MO2A-NORTH EL. SCALE:3/8" = 1'-0"7 MO2A-EAST EL. SCALE:3/8" = 1'-0"8 MO2A-SOUTH EL. SCALE:3/8" = 1'-0"9 TENANT SPACE 2 MO3- WEST ELEVATION SCALE:3/8" = 1'-0"10 TENANT SPACE 2 MO3- NORTH ELEVATION SCALE:3/8" = 1'-0"11 TENANT SPACE 2 MO3- EAST ELEVATION SCALE:3/8" = 1'-0"12 TENANT SPACE 2 MO3- SOUTH ELEVATION 1.PATCH ALL AREAS DAMAGED BY MEP REMOVALS, TYP. ASSUME 50 SF 2.PREP & PAINT EXPOSED CONDUIT TO MATCH WALL, TYP. GENERAL NOTES: REGISTRATION EXPIRES: 08/31/2028 EXISTING MASONRY WALL 5 8" GWB, PAINT FINISH FLOOR BASE, SEE FINISH SCHEDULE EXISTING ACT CEILING ACT CEILING TIE INTO EXISTING ACT 3 5 8" MINERAL WOOL INSULATION VAPOR RETARDER, SEAL TO FLOOR AND CEILING 3 5 8" LIGHT GAUGE METAL FRAMING ±9 ' - 0 " FIRST FLOOR STRUCTURE ABOVE ±1 2 ' - 0 " 1,4,5 TYPICAL 3'-0" V.I.F 03 CARRY 5 8" GWB ABOVE CEILING EXISTING MASONRY WALL 5 8" GWB, PAINT FINISH FLOOR BASE, SEE FINISH SCHEDULE 3 5 8" MINERAL WOOL INSULATION VAPOR RETARDER, SEAL TO FLOOR AND CEILING 3 5 8" LIGHT GAUGE METAL FRAMING ±9 ' - 0 " FIRST FLOOR STRUCTURE ABOVE ±1 2 ' - 0 " EXISTING CEILING, PAINT AS REQUIRED, ASSUME 3' 3'-0" V.I.F 03 LIGHT GAUGE METAL FRAMING AND 5/8" GWB, ALIGN WITH EXISTING CEILING PROVIDE SMOOTH TRANSITION. PAINT 5 8" GWB, PAINT FINISH FLOOR 3 5 8" MINERAL WOOL INSULATION VAPOR RETARDER, SEAL TO FLOOR AND CEILING BASE, SEE FINISH SCHEDULE EXISTING CEILING 3 5 8" LIGHT GAUGE METAL FRAMING GWB SOFFIT BEYOND. PATCH AND PAINT EXISTING SOFFIT ±1 1 ' - 8 " V . I . F . ±9 ' - 0 " FIRST FLOOR EXISTING MASONRY WALL 1,4,5 TYPICAL 03 LIGHT GAUGE METAL FRAMING AND 5/8" GWB, PAINT PROVIDE TRIM TO MATCH EXISTING. TYPICAL EXISTING MASONRY WALL 5 8" GWB, PAINT EXISTING 3 5 8" LIGHT GAUGE METAL FRAMING. V.I.F THAT FRAMING EXTENDS TO THE STRUCTURE ABOVE. FINISH FLOOR BASE, SEE FINISH SCHEDULE MINERAL WOOL INSULATION VAPOR RETARDER, SEAL TO FLOOR AND CEILING ±1 2 ' - 0 " ±9 ' - 0 " FIRST FLOOR AS REQUIRED, ASSUME 3' STRUCTURE ABOVE 3'-0" V.I.F EXISTING CEILING, PAINT 02 LIGHT GAUGE METAL FRAMING AND 5/8" GWB, ALIGN WITH EXISTING CEILING PROVIDE SMOOTH TRANSITION. PAINT EXISTING MASONRY WALL 5 8" GWB, PAINT 2" HAT CHANNEL FINISH FLOOR BASE, SEE FINISH SCHEDULE MINERAL WOOL INSULATION VAPOR RETARDER, SEAL TO FLOOR AND CEILING LIGHT GAUGE METAL FRAMING AND 5/8" GWB, ALIGN WITH EXISTING CEILING PROVIDE SMOOTH TRANSITION. PAINT EXISTING CEILING, PAINT ±1 2 ' - 0 " ±9 ' - 0 " FIRST FLOOR 3'-0" V.I.F AS REQUIRED, ASSUME 3' STRUCTURE ABOVE 01 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 7 : 0 9 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 WALL SECTIONS AND DETAILS A-301 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3112 BID DOCUMENTS SCALE:3/4" = 1'-0"4 WALL SECTION @ OFFICE 109 AND 110 SCALE:3/4" = 1'-0"3 WALL SECTION @ OFFICE 107 SCALE:3/4" = 1'-0"2 WALL SECTION @ SOFFIT ROOM 109 AND 110 SCALE:3/4" = 1'-0"5 WALL SECTION @ ROOM 104 SCALE:3/4" = 1'-0"1 WALL SECTION @ ROOM 103 PHOTO 3 WINDOW WELL OFFICE 107PHOTO 1 WINDOW WELL OFFICE 110 PHOTO 4 WINDOW WELL OFFICE 109PHOTO 2 WINDOW OFFICE 110 PHOTO 5 WINDOW WELL OFFICE 109 PHOTO 6 WINDOW WELL OFFICE 107 PHOTO 7 REST ROOM 104 SEE 8/A-101 SEE 8/A-101 SEE 8/A-101 SEE 8/A-101 REGISTRATION EXPIRES: 08/31/2028 105 CORRIDOR 3 STAIR 105-1 07 3-1 CABINET 2'-73 4"6'-0" 8'-73 4" 2' - 0 " 1' - 1 3 4" TRANSACTION WINDOW UNDERMOUNT SHELVING BRACKETS 16" O.C., TYP. SOLID SURFACE COUNTER TOP BULLET-RESISTANT FIBERGLASS PANEL DOOR OPERATOR BUTTON. DOOR 107-1 102 CORRIDOR 3' - 8 " 08 HINGED ACCESS COVER GROMMET PROVIDE BLOCKING FOR WALL-MOUNTED MONITOR BY OWNER 1' - 1 1 " A-501 9 A-501 8A-501 5 2'-73 4"6'-0" 8'-73 4" 8' - 1 1 " CABINET PAINT TRANSACTION WINDOW SOLID SURFACE COUNTER TOP 1" 2'-812" 3' - 0 " PROVIDE BLOCKING FOR WALL-MOUNTED MONITOR (BY OWNER) BASE, SEE FINISH SCHEDULE TRANSACTION DRAWER COUNTER TOP SUPPORT BRACKETS @ 18" O.C. PAINT TO MATCH WALL. PROVIDE BLOCKING AS REQ'D SOLID SURFACE COUNTERTOP GWB, PAINT BASE, SEE FINISH SCHDULE 2' - 8 3 4" 2'-812" A-501 7 COUNTER TOP SUPPORT BRACKETS @ 18" O.C., PAINT TO MATCH WALL. DO NOT IMPEDE OPERATION OF TRANSACTION DRAWER. PROVIDE BLOCKING AS REQ'D. TRANSACTION WINDOW TRANSACTION DRAWER 2 4 2 4 CABINET BACK 1 2" PLYWOOD WITH WOOD VENEER LAMINATE ONE SIDE AND BACKER AT 1 2 X 21 2" SOLID HARDWOOD BLOCKING. ANCHOR CASEWORK TO THE WALL 3/4" PLYWOOD, WITH WOOD VENEER LAMINATE ADJUSTABLE SHELF, 1/2" PLYWOOD, WITH WOOD VENEER LAMINATE ALL SIDES EXISTING CEILING CABINET TOP AND SIDES, 3/4" PLYWOOD, WITH WOOD VENEER LAMINATE 2'-0"BLOCKING AS REQ'D. 1 X TRIM, FINISH TO MATCH CABINET VENEER 5 44 NAILER A-501 6 312" 8' - 7 1 2" 8' - 1 1 " 4' - 3 3 4" 4' - 3 3 4" 3/4" PLYWOOD, WITH WOOD VENEER LAMINATE 1 2" SOLID SURFACE TOP AND SOLID SURFACE NOSING WITH PLYWOOD BASE. COORDINATE CUTOUT FOR TRANSACTION DRAWER ACCESS AND VIEW PANEL. TRANSACTION DRAWER U.L. RATED BULLET RESISTANT GLAZING, SEE SPEC. 1 3/4 " X 4" ALUMINUM TUBE WINDOW FRAME 107 OFFICE 105 CORRIDOR WALL TYPE SEE A-001 CONTINUOUS 1 2" BULLET-RESISTANT FIBERGLASS PANEL BOX BEAM LINTEL LIGHT GAUGE METAL FRAMING, SUPPORTING TRANSACTION DRAWER FINISH FLOOR ALUMINUM U-CHANNEL ALUMINUM U-CHANNEL 07 5 8" GWB 5 8" GWB 3' - 0 " 2' - 8 3 4" A-501 2 BASE, SEE FINISH SCHEDULE A-501 1 A-501 3 WALL TYPE SEE A-001 07 8"2'-0" 1 3/4 " X 4" ALUMINUM TUBE WINDOW FRAME ALUMINUM U-CHANNEL U.L. RATED BULLET-RESISTANT GLAZING BAFFLE WINDOW #10 - 3 1 2" FHP SCREWS TO SECURE FRAME IN OPENING 512" SEALANT ALL SIDES, TYP. 1 3 4" LIGHT GAUGE METAL BOX BEAM HEADER. FILL WITH INSULATION SEALANT ALL SIDES, TYP. #10 - 3 1 2" FHP SCREWS TO SECURE FRAME IN OPENING ALUMINUM U-CHANNEL U.L.RATED BULLET-RESISTANT VERTICAL BAFFLE TRANSACTION WINDOW 1 3 4" X 4" ALUMINUM TUBE 512" 5 8" GWB, TYP. SHIM 1 2" CONTINUOUS BULLET-RESISTANT FIBERGLASS PANEL LIGHT GAUGE METAL FRAMING. SEE WALL TYPE 07. FILL KING AND JACK STUDS WITH INSULATION 1 2" ALUMINUM U-CHANNEL 1 2" SOLID SURFACE TOP AND 3 4 SOLID SURFACE NOSING WITH 1 2" PLYWOOD BASE. CUT FOR TRANSACTION DRAWER LID, BEYOND TRANSACTION DRAWER U.L. RATED BULLET-RESISTANT GLAZING BAFFLE WINDOW 612" SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 4 7 : 2 9 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 ENLARGED FLOOR PLAN, SECTION AND DETAILS A-501 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3113 BID DOCUMENTS SCALE:1/2" = 1'-0"10 ENLARGED PLAN AT TRANSACTION WINDOW SCALE:1/2" = 1'-0"8 ELEVATION SCALE:1/2" = 1'-0"9 ELEVATION SCALE:1" = 1'-0"5 CABINET DETAIL SCALE:1" = 1'-0"6 CABINET ELEVATION SCALE:1" = 1'-0"7 SECTION @ TRANSACTION WINDOW SCALE:3" = 1'-0"1 TRANSACTION WINDOW HEAD DETAIL SCALE:3" = 1'-0"2 TRANSACTION WINDOW JAMB DETAIL SCALE:3" = 1'-0"3 TRANSACTION WINDOW SILL DETAIL REGISTRATION EXPIRES: 08/31/2028 EAST BUFFALO STREET 1910 NO R T H T I O G A S T R E E T 1910 1935 1965 POST OFFICE N.I.C. 1935 1965 OR LATER A A-600 B A-600 C A-600 RESTORED 4A4 W12 NEW REPLICA ± 2 ' - 1 1 " ±1'-11" PAINT WOOD SASH, FRAME & TRIM, PT-6, TYP. ATTIC WINDOW AT WALL CAP 4B W13 RESTORED & MODIFIED MECHANICAL EXHAUST IN CENTER PANE ± 2 ' - 1 1 " ±1'-11" PAINT WOOD SASH, FRAME & TRIM, PT-6, TYP. SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 5 0 : 4 8 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 KEY PLAN AND ELEVATIONS A-601 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3114 BID DOCUMENTS SCALE:1/16" = 1'-0"3 KEY ROOF PLAN'C' WEST ELEVATION 'B' PARTIAL SOUTH ELEVATION 'A' NORTH ELEVATION SCOPE OF WORK SUMMARY INTENT OF THIS PROJECT IS TO RESTORE AND WEATHER SEAL WINDOWS CONSISTENT WITH THE SECRETARY OF THE INTERIOR STANDARDS FOR THE TREATMENTS OF HISTORIC PROPERTIES. ITEM #1 - WINDOWS IN THE 1910 HISTORICALLY SIGNIFICANT SECTION OF THE BUILDING SHALL BE RESTORED, EXCLUDING THE BASEMENT. OPERABLE SASHES TO BE REMOVED, LOOSE PAINT CAREFULLY SCRAPED, SASHES REPAIRED OR REPLACED WITH WOOD DUTCHMANS AS NECESSARY TO MATCH THE EXISTING. EXISTING SINGLE PANE GLAZING TO BE REPLACED WITH NEW CLEAR LOW IRON GLASS IGU (WITH LOW-E COATING). WITHIN THE COURT OFFICES AND RESTROOMS APPLY NEW INTERIOR PRIVACY FILM. SASH WEIGHTS TO BE REMOVED AND THE WEIGHT POCKETS FILLED WITH LOW RISE EXPANDING FOAM TO AIR SEAL. SINGLE AND DOUBLE HUNG UNITS WILL BE MADE FIXED UNITS. SASHES WILL BE AIR SEALED WITH NEW CONCEALED MASTIC. EXTERIOR AND INTERIOR WOOD FRAMES TO BE PAINTED TO MATCH WITH NEW SEALANTS INSTALLED AROUND THE PERIMETER. REFER TO TYPICAL WINDOW DETAILS ON A-701. INTERIOR CASING TRIM TO BE REPLACED IN KIND. #2 - NOT USED #3 - REMOVE AND REPLACE THE EXISTING WOOD WINDOW, FRAME AND SASH WITH NEW WOOD WINDOW TO MATCH ORIGINAL. #4 - ATTIC WINDOW. SASHES TO BE REMOVED, LOOSE PAINT CAREFULLY SCRAPED, SASHES REPAIRED OR REPLACED WITH WOOD DUTCHMANS AS NECESSARY TO MATCH THE EXISTING. EXISTING SINGLE PANE GLAZING TO BE REPLACED WITH NEW CLEAR LOW-IRON GLASS IGU (WITH LOW-E COATING). EXTERIOR AND INTERIOR WOOD FRAMES TO BE PAINTED TO MATCH WITH NEW SEALANTS INSTALLED AROUND THE PERIMETER. #4A - ATTIC WINDOW. REMOVE EXISTING LOUVER AND REPLACE WITH NEW SASH TO MATCH ORIGINAL WITH NEW CLEAR LOW-IRON GLASS IGU (WITH LOW-E COATING). EXTERIOR AND INTERIOR WOOD FRAMES TO BE PAINTED TO MATCH WITH NEW SEALANTS INSTALLED AROUND THE PERIMETER. #4B - CENTER PANE TO BE CONVERTED FOR MECHANICAL INTAKE/EXTRACT. COORDINATE WITH M-SERIES. SASH TO BE REMOVED AND REPLACED WITH NEW SASH TO MATCH ORIGINAL WITH NEW CLEAR LOW-IRON GLASS IGU (WITH LOW-E COATING). LOOSE PAINT CAREFULLY SCRAPED, SASH REPAIRED OR REPLACED WITH WOOD DUTCHMANS AS NECESSARY TO MATCH THE EXISTING. EXTERIOR AND INTERIOR WOOD FRAMES TO BE PAINTED TO MATCH THE EXISTING. INSTALL SEALANT AT PERIMETER FOR AIRTIGHTNESS. 1 2 3 4 4A 3 3 4B 1 N.I.C N.I.C 4B 4 4 4 4A 4A 4B 444 GLAZING TO HAVE PRIVACY FILM APPLIED 1 1111 GLAZING TO HAVE PRIVACY FILM APPLIED 11 4B N.I.C N.I.C.N.I.C.N.I.C. N.I.C.N.I.C.N.I.C.N.I.C. N.I.C.N.I.C. SCALE:1/2" = 1'-0"1 ATTIC WINDOW ELEVATION SCALE:1/2" = 1'-0"2 ATTIC @ WALL CAP REFER TO SCOPE ITEM #4 AND #4A N.I.C N.I.C REGISTRATION EXPIRES: 08/31/2028 20 ' - 2 " 2' - 7 " V . I . F . 8' - 3 " V . I . F . 2' - 9 " V . I . F . 4' - 1 1 2" V . I . F . 7'-2" V.I.F. 11 ' - 0 " V . I . F EXISTING 1 W8 W7 W8 W6 W5 W6 PAINT WOOD SASH, FRAME & TRIM, PT-1, TYP. 20 ' - 2 " 7'-2" V.I.F. 2' - 6 1 4" V . I . F . 8' - 3 " V . I . F . 2' - 9 " V . I . F . 4' - 1 12" V . I . F . 11 ' - 0 " V . I . F EXISTING 1 W8 W7 W8 W6 W5 W6 PAINT WOOD SASH, FRAME & TRIM, PT-6, TYP. INTERIOREXTERIOR 2' - 1 1 3 4"V . I . F . 1'-0"V.I.F. 1" 1" NEW W11 W11 PAINT WOOD SASH, FRAME & TRIM, PT-6, TYP. FRAME & TRIM, TYP. SEE FINISH SCHEDULE SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 5 1 : 0 8 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 WINDOW ELEVATIONS A-602 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3115 BID DOCUMENTS SCALE:1/2" = 1'-0"5 1910 WINDOW INTERIOR ELEVATION AT LOBBY SCALE:1/2" = 1'-0"4 1910 WINDOW EXTERIOR WEST ELEVATION SCALE:1" = 1'-0"1 1910 SMALL WINDOW ELEVATION WEST ELEVATIONSOUTH ELEVATION SMALL WINDOW SEE 1/A-101 NOTES: - CONTRACTOR TO FIELD VERIFY ALL DIMENSIONS - BUILDING IS ON THE NATIONAL REGISTER. VINTAGES FROM 1910 & 1935 ARE CONSIDERED SIGNIFICANT. REFER TO SCOPE ITEM #1 AND #2 REFER TO SCOPE ITEM #3 3 3 SCOPE OF WORK SUMMARY ITEM #1 AND #2 - WINDOWS IN THE 1910 HISTORICALLY SIGNIFICANT SECTION OF THE BUILDING SHALL BE RESTORED. OPERABLE SASHES TO BE REMOVED, LOOSE PAINT CAREFULLY SCRAPED, SASHES REPAIRED OR REPLACED WITH WOOD DUTCHMANS AS NECESSARY TO MATCH THE EXISTING. EXISTING SINGLE PANE GLAZING TO BE REPLACED WITH NEW CLEAR LOW IRON GLASS IGU (WITH LOW E COATING). WITHIN THE COURT OFFICES AND RESTROOMS APPLY NEW INTERIOR PRIVACY FILM. SASH WEIGHTS TO BE REMOVED AND THE WEIGHT POCKETS FILLED WITH LOW RISE EXPANDING FOAM FOR AIR SEAL. HUNG SINGLE AND DOUBLE HUNG UNITS WILL BE MADE FIXED UNITS. SASHES WILL BE AIR SEALED WITH NEW CONCEALED MASTIC. EXTERIOR AND INTERIOR WOOD FRAMES TO BE PAINTED TO MATCH EXISTING WITH NEW SEALANTS INSTALLED AROUND THE PERIMETER. REFER TO TYPICAL WINDOW DETAILS ON A701. THE SCOPE OF THIS PROJECT INCLUDES INTERIOR SIDE INSULATION UPGRADES AND NEW WALL FURRING. INTERIOR TRIM TO BE REPLACED IN KIND. #3 - REMOVE AND REPLACE THE EXISTING WOOD WINDOW, FRAME AND SASH WITH NEW WOOD WINDOW TO MATCH EXISTING SIGHTLINES. 2 3 1 REGISTRATION EXPIRES: 08/31/2028 EXISTING MASONRY WALL EXISTING STONE SILL WOOD STOOL, MATCH EXISTING PAINT WOOD TRIM MATCH EXISTING, PAINT REPLACEMENT 7 16" IGU GWB, PAINT WALL ASSEMBLY SEE 1/A-001 WOOD TRIM MATCH EXISTING, PAINT VAPOR RETARDER, SEAL TO WINDOW FRAME GLAZING PUTTY INTERIOR STOP TO BE ROUTED BACK TO RECEIVE IGU ± 10" V.I.F. FRAME TO REMAIN RESTORED SASH 03 GWB, PAINT WALL ASSEMBLY SEE 1/A-001 PROVIDE WOOD TRIM MATCH EXISTING, PAINT EXTENSION JAMB, PAINT REPLACEMENT 7 16" IGU PROVIDE WOOD TRIM MATCH EXISTING, PAINT FILL WEIGHT POCKETS W/ CCSF FOR AIR TIGHTNESS EXISTING MASONRY WALL VAPOR RETARDER, SEAL TO WINDOW FRAME EXISTING STONE SILL, BEYOND GLAZING PUTTY INTERIOR STOP TO BE ROUTED BACK TO RECEIVE IGU FRAME TO REMAIN RESTORED SASH 03 GWB, PAINT WALL ASSEMBLY SEE 1/A-001 PROVIDE WOOD TRIM MATCH EXIST., PAINT EXTENSION JAMB, PAINT FILL WEIGHT POCKETS W/ CCSF FOR AIR TIGHTNESS PROVIDE WOOD TRIM MATCH EXISTING, PAINT EXISTING MASONRY WALL VAPOR RETARDER, SEAL TO M.O. REPLACEMENT IGU GLAZING PUTTY INTERIOR STOP TO BE ROUTED BACK TO RECEIVE IGU ±7 3 4" V . I . F . FRAME TO REMAIN RESTORED SASH 03 1 2"3'-0"2" 2" 7' - 0 " A-701 2 A-701 6 A-701 4 A-701 8 A-701 3 A-701 7 6" H.M. FRAME, PAINT SEALANT ALL SIDES EXISTING WALL 6" JAMB ANCHOR (3 PER JAMB, TYP.) SEALANT ALL SIDES, TYP. H.M. FRAME, PAINT 2" EXISTING WALL DO NOT DISTURB MARBLE IN LOBBY 7' - 0 " 3'-0" A B 7' - 0 " 3'-0" 7' - 0 " 2'-6" C G-1 1'-10" 1' - 1 1 " ±7 ' - 6 " ±7 ' - 6 " ±3'-10"±1'-5"±2'-2"±1'-5" ±7 ' - 7 " ±7 ' - 7 " ±3'-10"±1'-5"±2'-7"±1'-5" ±3 ' - 4 12" ±3 ' - 1 3 4" ±3 ' - 2 " ±2 ' - 1 0 3 4"± R 3 ' - 6 14" ± R 3 ' - 1 1 4" ± R 3 ' - 6 14" ± R3'- 1 14" ±2 ' - 1 0 1 2" ±2'-3" W8W7W4W3 W12 W6W5W2W1 1 ±2 ' - 1 0 12" ±2'-3" W13 WALL CAPS FOR NEW AIR TERMINALS. COORDINATE WITH M-SERIES IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 IG-1 F-1 F-1 F-1 F-1 F-1 F-1 IG-1 IG-1 F-1 F-1 REPLACEMENT IGUHEAD EXISTING MASONRY WALL MINERAL WOOL INSULATION SMART VAPOR RETARDER SEAL TO WINDOW FRAME SILL REPLACEMENT IGU EXISTING MASONRY WALL MINERAL WOOL INSULATION SMART VAPOR RETARDER EXISTING MASONRY WALL JAMB REPLACEMENT IGU MINERAL WOOL INSULATION SMART VAPOR RETARDER SEAL TO WINDOW FRAME SEALANT H.M. FRAME, FILL WITH MINERAL WOOL INSULATION 5 8" GWB TO EXTEND TO CEILING 5 8" GWB PAINT.PROVIDE SMOOTH TRANSITION TO EXISTING WALL. LIGHT GAUGE METAL BOX BEAM SEALANT 1 2" BULLET- RESISTANT FIBERGLASS PANEL, EXTEND TO CEILING V.I.F. ± 6 " EXISTING WALL V. I . F . DOOR SEE SCHED. ±73 4" V.I.F. V. I . F . ± 6" SEE PLAN ±7 3 4" V . I . F . DOOR SEE SCHED.5 8" GWB, PAINT SEALANT, TYP. 1 2" BULLET-RESITANT FIBERGLASS PANEL 2" EXISTING WALL 5 8" GWB, PAINT. PROVIDE SMOOTH TRANSITION TO EXISTING WALL PROVIDE J BEAD TRIM DOOR SEE SCHED. H.M. FRAME ANCHOR TO LIGHT GAUGE METAL PARTITION 5 8' GWB, PAINT LIGHT GAUGE METAL BOX BEAM SEALANT BOTH SIDES DOOR, SEE SCHED. H.M. FRAME ANCHOR TO LIGHT GAUGE METAL PARTITION SEALANT BOTH SIDES 5 8' GWB, PAINT LIGHT GAUGE METAL BOX BEAM SHIM DOOR, SEE SCHED. REINSTALL EXISTING FRAME TRIM, MATCH IN KIND. PAINT BOTH SIDES EXISTING WALL 2 2X6 AND BLOCKING 5 8" GWB, PAINT. PROVIDE SMOOTH TRANSITION WITH EXISTING WALL 1 2" SHIM 2 6 2 6 2 4 2 4 DOOR, SEE SCHED. TRIM, MATCH IN KIND. PAINT BOTH SIDES 5 8" GWB PROVIDE SMOOTH TRANSITION WITH EXISING WALL. BOTH SIDES 2 2X4 EXISTING WALL 1 2" SHIM REINSTALL EXISTING FRAME ±2 ' - 1 1 3 4" VI F W11 IG-1 IG-1 F-1 F-1 1'-0" VIF 3' - 0 3 4" R O , V I F 1'-1" RO, VIF SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 11 / 7 / 2 0 2 5 1 1 : 5 2 : 0 4 A M /HE A T H E R V E N D I T T I Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204Pittsford, NY 14534 Suite 201 WINDOW AND DOOR DETAILS AND DOOR AND FRAME TYPES A-701 10/24/2025 HHV DE 716-23-002 TO W N O F I T H A C A 2 N D F L O O R & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : A A 1 6 2 0 . 5 1 7 3116 BID DOCUMENTS SCALE:1 1/2" = 1'-0"11 TYPICAL WINDOW SILL DETAIL SCALE:1 1/2" = 1'-0"10 TYPICAL WINDOW JAMB DETAIL SCALE:1 1/2" = 1'-0"1 TYPICAL WINDOW HEAD DETAIL SCALE:1/4" = 1'-0"16 DOOR TYPES SCALE:3" = 1'-0"2 HEAD DETAIL SCALE:3" = 1'-0"6 JAMB DETAIL SCALE:1/4" = 1'-0"14 WINDOW SASH TYPES SCALE:1 1/2" = 1'-0"12 ATTIC WINDOW DETAILS EXISTING WINDOW FRAME AREA OF MODIFICATION: INTERIOR STOP TO BE ROUTED BACK APPROX. 5 16" TO 3 8" TO RECEIVE IGU V.I.F ALL DIMENSIONS SCALE:3" = 1'-0"3 HEAD DETAIL DOOR 107-1 SCALE:3" = 1'-0"7 JAMB DETAIL DOOR 107-1 SCALE:3" = 1'-0"4 HEAD DETAIL DOOR MO2-2 SCALE:3" = 1'-0"8 JAMB DETAIL DOOR MO2-2 SCALE:3" = 1'-0"5 HEAD DETAIL DOOR MO2A-1 SCALE:3" = 1'-0"9 JAMB DETAIL DOOR MO2A-1 SCALE:1/4" = 1'-0"13 WINDOW TYPE SCALE:1/4" = 1'-0"15 FRAME TYPE NOTE: PATCH ALL HOLES MADE FROM SPRAY FOAM, TYPICAL. FINISH TO MATCH SURROUNDING REGISTRATION EXPIRES: 08/31/2028 RECIRCULATION HOT COLD VENT WASTE BELOW FLOOR WASTE SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 4 8 : 5 5 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 5 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 BALL VALVE CLOSED VENT THRU ROOF BALL VALVE OPEN CHECK VALVE THERMOMETER CIRCULATOR CONNECT TO EXISTING LEGEND & NOTES GS YB PLUMBING FIXTURE SCHEDULE MARK MANUF MODEL DESCRIPTION NOTES WC-1 AMERICAN STANDARD 215AA.104 ELONGATED BOTTOM OUTLET TWO-PIECE ADA FLUSH TANK TOILET, 1.28 GPF, EPA WATER SENSE, 1000G MAP SCORE, WITH CHAIR HEIGHT BOWL PROVIDE WITH WC-1.1 WC-1.1 AMERICAN STANDARD 5901.110 ELONGATED HEAVY DUTY BOWL OPEN FRONT SEAT LESS COVER WITH EVERCLEAN SURFACE INSTALL WITH WC-1 WC-2 EXISTING EXISTING EXISTING TOILET AND FLUSH VALVE UR-1 AMERICAN STANDARD 6550.001 UNIVERSAL URINAL; VITREOUS CHINA, FLUSHING RIM, SIPHON JET FLUSH, 3 4" INLET AND 2" OUTLET CONNECTIONS PROVIDE WITH UR-1.1 AND UR-1.2 UR-1.1 SLOAN ROYAL 186-0.5 0.5 GPF POLISHED CHROME FLUSHOMETER. ADA COMPLIANT, TOP SPUD CONNECTION.INSTALL WITH UR-1 UR-1.2 ZURN Z1222 WALL URINAL SUPPORT SYSTEM WITH TOP SUPPORT PLATE AND LOWER BEARING PLATE.INSTALL WITH UR-1 AND UR-1.1 L-1 EXISTING EXISTING EXISTING LAVATORY AND LAVATORY FAUCET L-1.1 ZURN Z1221 LAVATORY SUPPORT SYSTEM WITH TOP SUPPORT PLATE.INSTALL WITH RELOCATED LAVATORY WATER HEATER SCHEDULE TYPE MANUFACTURER MODEL DESCRIPTION DIMENSIONS, IN WEIGHT, LBS TYPE FUEL MIN. FLOW TO ACTIVATE TEMP. RISE ENERGY FACTORY VOLTAGE PHASE WATTS NOTES WH-1 STIEBEL ELTRON 232099 INSTANTANEOUS WATER HEATER 7.5"(W) X 6.5"(H) X 3.25"(D)3.44 ELECTRIC 0.40 GPM 48 °F 0.99 120 V 1 3.5 KW N/A LEGEND2020 IECC COMPLIANCE CODE SECTION COMPLIANCE C404.2 WATER-HEATING EQUIPMENT AND HOT WATER STORAGE TANKS MEET OR EXCEED THE REQUIREMENTS OF TABLE C404.2 C404.4 PIPING INSULATION SHALL BE IN ACCORDANCE WITH TABLE C403.11.3 C404.5 HEATED WATER SUPPLY PIPING SHALL BE IN ACCORDANCE WITH SECTION C404.5.1 OR C404.5.2 C404.6 HEATED WATER CIRCULATION SHALL BE IN ACCORDANCE WITH SECTION C404.6.1. HEAT TRACE TEMPERATURE MAINTENANCE SYSTEMS SHALL BE IN ACCORDANCE WITH SECTION C404.6.2. CONTROLS FOR HOT WATER STORAGE SHALL BE IN ACCORDANCE WITH SECTION C404.6.3. P-001 DEMOLITION EXISTING 02/27/2025 17 31 32 10/24/2025 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE L-1 WC-2 WC-2 WC-2 WC-2 L-2 L-2 3 33 3 4 5 6 7 M02A RESTROOM M01 CORRIDOR M03 TENATE SPACE 2 M02 TENANT SPACE 1 1 2 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 4 9 : 0 1 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 PLUMBING DEMOLITION PLANS GS YB Scale: 1/4"=1'-0" FIRST FLOOR DEMOLITION PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR DEMOLITION PLAN2 PD-101 1.ALL DEMO WORK THAT IMPACTS THE USE OF THE WHOLE BUILDING SHALL BE CONDUCTED ON SATURDAYS AND SUNDAYS IN ORDER TO MAINTAIN PROPER USE CASE OF THE BUILDING. DEMOLITION KEYNOTES NUMBER NOTE 1 DECOMMISSION DCW AND DHW PIPING. CAP AND DRAIN DCW AND DHW PIPING IN MEZZANINE BATHROOM. DISCONNECT AND CAP PIPING IN BASEMENT. LEAVE DCW AND DHW PIPING IN WALL. 2 REMOVE EXISTING FLUSH TANK TOILET, LAVATORY, LAVATORY FAUCET, AND TRAP. CAP EXISTING SANITARY TO NEAREST FITTING FOR FUTURE CONNECTIONS. IF VENT FROM MAIN STACK IS OBSTRUCTED DUE TO THE CAP PROVIDED TO SANITARY FITTINGS, TEMPORARY VENT PIPING SHALL BE INSTALLED TO MAINTAIN STACK BETWEEN DEMO AND NEW CONSTRUCTION PHASES. 3 REMOVE AND RETAIN EXISTING FLUSH VALVE TOILETS. CLEAN FIXTURES FOR LATER REUSE. DEMOLISH SANITARY. DISCONNECT, CAP AND VALVE DCW PIPING FOR FUTURE CONNECTIONS. 4 LAVATORY EXISTING TO REMAIN. KEEP EXISTING SANITARY RISER IN WALL AND VENT CONNECTION. 5 REMOVE AND RETAIN EXISTING LAVATORY, LAVATORY FAUCET AND P-TRAP. CLEAN FIXTURE FOR LATER REUSE. DISCONNECT AND CAP EXISTING SANITARY AND VENT PIPING. ENSURE VENT PIPING CAN BE USED LATER FOR FUTURE CONNECTION. DICONNECT, CAP AND VALVE DCW AND DHW PIPING FOR FUTURE CONNECTIONS. 6 REMOVE AND DISPOSE OF EXISTING FLUSH VALVE TOILET. DEMOLISH AND CAP EXISTING SANITARY AND VENT PIPING TO NEAREST FITTING. DEMOLISH DCW PIPING ROUTED TO FIXTURE, CAP AND VALVE AT TERMINATION POINT. 7 REMOVE AND RETAIN EXISTING LAVATORY, LAVATORY FAUCET AND P-TRAP. CLEAN FIXTURE FOR LATER REUSE. DEMOLISH AND CAP EXISTING SANITARY AND VENT PIPING TO NEAREST FITTING. DEMOLISH DCW AND DHW PIPING ROUTED TO FIXTURE, CAP AND VALVE AT TERMINATION POINT. PLUMBING GENERAL NOTES 2.ONE PUBLIC RESTROOM SHALL REMAIN OPEN AND ACCESSIBLE FOR USE AT ALL TIMES. 02/27/2025 18 31 32 10/24/2025 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR 8 UR-1 7 6 6 WC-2 L-2 L-2 WC-2 WC-2 11 9 11 M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM WC-1 L-1 1 3 2 WH-1 4 5 FC-1 FC-2 10 10 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 4 9 : 0 5 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 PLUMBING FLOOR PLANS GS YB Scale: 1/4"=1'-0" FIRST FLOOR PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR PLAN2 P-101 1.ALL NEW WORK THAT IMPACTS THE USE OF THE WHOLE BUILDING SHALL BE CONDUCTED ON SATURDAYS AND SUNDAYS IN ORDER TO MAINTAIN PROPER USE CASE OF THE BUILDING. 2.PLUMBING FIXTURES TO BE INSTALLED AND MOUNTED BY PLUMBING CONTRACTOR. GENERAL CONTRACTOR TO INSTALL ALL NECESSARY BLOCKING. GC TO PERFORM ALL CORE DRILLING. COORDINATE LOCATIONS WITH GC. 3.ONE PUBLIC RESTROOM SHALL REMAIN OPEN AND ACCESSIBLE FOR USE AT ALL TIMES. KEYNOTES NUMBER NOTES 1 PROVIDE NEW CONDENSATE RECEPTOR IN RESTROOM FOR NEW MECHANICAL EQUIPMENT. PROVIDE NEW SANITARY PIPING FOR CONDENSATE DRAIN. CONNECT NEW SANITARY PIPING INTO EXISTING SANITARY RISER. CONNECT CONDENSATE PIPING FROM FC-1 AND FC-2 TO CONDENSATE DRAIN. 2 PROVIDE NEW FLUSH TANK TOILET (WC-1) AND CONNECT INTO NEW SANITARY AND DOMESTIC WATER CONNECTIONS. 3 REINSTALL LAVATORY L-1 RETAINED FROM DEMO, USING L-1.1 CARRIER MOUNT IN WALL. LAVATORY AND LAVATORY FAUCET SAVED FROM OFFICE 109 BATHROOM. PROVIDE NEW P-TRAP AND KNEE GAURD FOR LAVATORY. CONNECT INTO EXISTING CAPPED SANITARY AND VENT PIPING AND NEW DOMESTIC WATER CONNECTIONS. 4 PROVIDE A NEW INSTANTANEOUS WATER HEATER (WH-1) UNDERNEATH OR NEXT TO THE LAVATORY. SUPPLY THE LAVATORY WITH A 1/2" DHW LINE FROM THE WATER HEATER. 5 PROVIDE NEW 3/4" DCW LINE IN FURRED OUT WALL, ROUGHLY 25' OF PIPE WILL BE REQUIRED. CONNECT NEW LINE INTO EXISTING DCW DISTRIBUTION IN THE BASEMENT. USE NEW LINE TO SUPPLY TOILET, LAVATORY, AND WATER HEATER WITH 1/2" DCW CONNECTIONS. 6 REINSTALL LAVATORY, LAVATORY FAUCET AND P-TRAP RETAINED FROM DEMO, CONNECT INTO EXISTING SANITARY AND VENT PIPING. PROVIDE NEW DOMESTIC WATER PIPING TO CONNECT INTO EXISTING DOMESTIC WATER DISTRIBUTION. 7 INSTALL UR-1 WITH UR-1.1 AND UR-1.2. UR-1.2 CARRIER IS INSTALLED IN WALL CAVITY AND MOUNTED TO FLOOR. 8 WET VENT WATER CLOSET AND URINAL THROUGH EXISTING LAVATORY VENT. 9 CONNECT NEW FIXTURES INTO EXISTING DOMESTIC WATER DISTRIBUTION THAT WAS CAPPED AND VALVED DURING DEMO. PROVIDE NEW DOMESTIC WATER PIPING WHERE NECESSARY TO REACH NEW FIXTURE FROM THE CAPPED DOMESTIC WATER PIPE. 10 ROUTE 3 4" CONDENSATE PIPING FROM FC TO CONDENSATE RECEPTOR. PIPING SHALL BE ROUTED WITHIN FURRED OUT WALL. SLOPE PIPING AT 1 8" / 12" TOWARDS THE DROP TO THE CONDENSATE RECEPTOR IN RESTROOM M02A. 11 REINSTALL FLUSH VALVE TOILET WC-2 RETAINED FROM DEMO, CONNECT INTO EXISTING DOMESTIC WATER DISTRIBUTION THAT WAS CAPPED AND VALVED DURING DEMO. PROVIDE NEW DOMESTIC WATER PIPING WHERE NECESSARY TO REACH NEW FIXTURE FROM THE CAPPED DOMESTIC WATER PIPE. PLUMBING GENERAL NOTES 02/27/2025 19 31 32 10/24/2025 100 NODE NUMBER SIDEWALL SPRINKLER RECESSED PENDENT SPRINKLER UPRIGHT SPRINKLER LEGEND CONNECT TO EXISTING EXISTING (HALF TONE) DEMOLITION SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 9/ 2 5 / 2 0 2 5 2 : 0 8 : 2 3 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 LEGEND AND NOTES BAM YB FP-001 The following are the documentation requirements for Fire Sprinkler Systems as required by the Fire Code of NYS and the Town of Ithaca. Drawings to be provided to the Town of Ithaca Code Enforcement Department. A.Working Plans shall be drawn to an indicated scale, on sheets of uniform size, with a plan of each floor, and shall show those items from the following list that pertain to the design of the system: 1.Name of owner and occupant. 2.Location, including street address. 3.Point of compass. 4.Full height cross section, or schematic diagram, including structural member information if required for clarity and including ceiling construction and method of protection for nonmetallic piping. 5.Location of partitions. 6.Location of fire walls. 7.Occupancy class of each area or room. 8.Location and size of concealed spaces, closets, attics, and bathrooms. 9.Any small enclosures in which no sprinklers are to be installed. 10.Size of city main in street and whether dead end or circulating; if dead end, direction and distance to nearest circulating main; and city main test results and system elevation relative to test hydrant (see A.23.1.8). 11.Other sources of water supply, with pressure or elevation. 12.Make, type, model, and nominal K‐factor of sprinklers including sprinkler identification number. 13.Temperature rating and location of high temperature sprinklers. 14.Total area protected by each system on each floor. 15.Number of sprinklers on each riser per floor. 16.Total number of sprinklers on each dry pipe system, preaction system, combined dry pipe‐preaction system, or deluge system. 17.Approximate capacity in gallons of each dry pipe system. 18.Pipe type and schedule of wall thickness. 19.Nominal pipe size and cutting lengths of pipe (or center to center dimensions). Where typical branch lines prevail, it shall be necessary to size only one typical line. 20.Location and size of riser nipples. 21.Type of fittings and joints and location of all welds and bends. The contractor shall specify on drawing any sections to be shop welded and the type of fittings or formations to be used. 22.Type and locations of hangers, sleeves, braces, and methods of securing sprinklers when applicable. 23.All control valves, check valves, drain pipes, and test connections. 24.Make, type, model, and size of alarm or dry pipe valve. 25.Make, type, model, and size of preaction or deluge valve. 26.Kind and location of alarm bells. 27.Size and location of standpipe risers, hose outlets, hand hose, monitor nozzles, and related equipment. 28.Private fire service main sizes, lengths, locations, weights, materials, point of connection to city main; the sizes, types and locations of valves, valve indicators, regulators, meters, and valve pits; and the depth that the top of the pipe is laid below grade. 29.Piping provisions for flushing. 30.Where the equipment is to be installed as an addition to an existing system, enough of the existing system indicated on the plans to make all conditions clear. 31.For hydraulically designed systems, the information on the hydraulic data nameplate. 32.A graphic representation of the scale used on all plans. 33.Name and address of contractor. 34.Hydraulic reference points shown on the plan that correspond with comparable reference points on the hydraulic calculation sheets. 35.The minimum rate of water application (density or flow or discharge pressure), the design area of water application, in‐rack sprinkler demand, and the water required for hose streams both inside and outside. 36.The total quantity of water and the pressure required noted at a common reference point for each system. 37.Relative elevations of sprinklers, junction points, and supply or reference points. 38.If room design method is used, all unprotected wall openings throughout the floor protected. 39.Calculation of loads for sizing and details of sway bracing. 40.The setting for pressure reducing valves. 41.Information about backflow preventers (manufacturer, size, type). 42.Information about antifreeze solution used (type and amount). 43.Size and location of hydrants, showing size and number of outlets and if outlets are to be equipped with independent gate valves. Whether hose houses and equipment are to be provided, and by whom, shall be indicated. Static and residual hydrants that were used in flow tests shall be shown. 44.Size, location, and piping arrangement of fire department connections. 45.Ceiling/roof heights and slopes not shown in the full height cross section. 46.Edition year of NFPA 13-2016 that the sprinkler system is designed to. The Detailed worksheets or computer printout sheets shall contain the following information: 1.Sheet number 2.Sprinkler description and discharge constant (K) 3.Hydraulic reference points 4.Flow in gpm (L/min) 5.Pipe size 6.Pipe lengths, center to center of fittings 7.Equivalent pipe lengths for fittings and devices 8.Friction loss in psi/ft (bar/m) of pipe 9.Total friction loss between reference points 10.In-rack sprinkler demand balanced to ceiling demand 11.Elevation head in psi (bar) between reference points 12.Required pressure in psi (bar) at each reference point 13.Velocity pressure and normal pressure if included in calculations 14.Notes to indicate starting points or reference to other sheets or to clarify data shown 15.Diagram to accompany gridded system calculations to indicate flow quantities and directions for lines with sprinklers operating in the remote area 16.Combined K-factor calculations for sprinklers on drops, armovers, or sprigs where calculations do not begin at the sprinkler Sprinkler system components shall be listed and approved for the purpose for which they are installed. All underground connections, above ground piping, and in building piping shall be inspected, hydrostatically tested, and flushed per the requirements of NFPA 13-2016 and the Fire Code of New York State. Town of Ithaca shall perform all inspections. The Town of Ithaca shall witness all flushing of piping, and testing of alarm devices. All hydrostatic testing shall be performed prior to any sprinkler piping being concealed by walls, ceilings, or other obstructions from visual inspection. The Town of Ithaca, prior to the underground service being concealed, shall witness hydrostatic testing and flushing of underground water services. Upon completion of the installation, the contractor shall submit a written statement to the Town of Ithaca that the system has been installed in accordance with approved plans and tested in accordance with the manufacturer's specifications, and the appropriate NYS and NFPA 13-2016 requirements. TOWN OF ITHACA DOCUMENTATION REQUIREMENTS SYSTEM TEST DATA TEST DATE: 3/14/2024 STATIC: 85 PSI RESIDUAL: 70 PSI TEST STATUS: PASS GENERAL A.Provide a complete wet pipe fire sprinkler system per the latest edition of NFPA 13-2016, applicable codes, and the specifications. B.Sprinkler design is performance based. Contractor shall design system subject to approval by AHJ, perform all hydraulic calculations, and submit stamped working drawings. Drawings shall be stamped by Engineer Licensed in the State of New York. C.Submit product data for valves, sprinklers, specialties, and alarms. D.Occupancy is light hazard. E.Concealed spaces above suspended ceilings are non-combustible per NFPA 13-2016 and do not require sprinklers. F.Installation shall be made with piping run level plumb. And square to building structure in a neat manner. Changes in direction shall be made with proper pipe fittings. G.The sprinkler layout, sizing, and routing are diagrammatic to represent the scope of work. Piping shown is illustrative of intended piping locations. Contractor shall field determine all sprinkler locations, positions, pipe routing, sizing, and accessories to provide a fully sprinklered building. H.Comply with NFPA 13-2016. I.Use UL listed and labeled and FM approved pipe and fittings. J.Comply with the fire code of New York State section 901.7 systems out of service. Notify fire department and code enforcement official. K.Provide supervision of valves and flow switches. L.Means shall be provided downstream of all backflow prevention valves for flow tests at system demand M.The contractor shall arrange for all necessary hydrant flow tests and system inspections with the Town of Ithaca. N.The contractor shall verify elevator shaft sprinkler requirements with elevator manufacturer and local code official. CEILINGS A.Ceiling type and heights are noted on the architectural drawings. Contractor shall verify ceiling and sprinkler installation details prior to final design of system. B.Conceal sprinkler piping above suspended ceiling as indicated and wherever space permits. Center sprinklers in ceiling tiles as closely as possible. Minimum distance from grid to sprinkler is 6". C.Provide concealed sprinklers in all finished ceilings. PIPING A.The architect/engineer/owner shall be notified of conflicts in sprinkler system location prior to installation of conflicting elements. B.Paint all exposed piping & fittings. Clean pipe surface free of excess oils, pipe joint compound, and debris to accept painting. Apply two coats of color selected by owner. C.All trapped piping shall be fitted with a plugged outlet for draining. Provide drain valves wherever necessary to permit complete drainage of system. D.Provide inspector test connections for testing and drainage purposes as required by NFPA 13-2016. E.Provide hangers and seismic restraint per NFPA 13-2016 throughout. F.All piping penetrations through masonry walls and floors shall be core drilled. Vacuum drilling bases shall be used to prevent damage to the walls. G.Fire seal all pipe penetrations through fire rated partitions and floors at both ends with elastomer fire caulk. H.Furnish and install split, chrome plated steel, floor and ceiling plates for all exposed pipe penetrations through walls and ceilings. I.The contractor shall coordinate locations of standpipe and combined sprinkler/standpipe risers, valves and accessories locations with architect to maintain required stair landing clearances. STANDPIPES DURING CONSTRUCTION A.In buildings required to have standpipes, not less than one standpipe shall be provided for use during construction. Such standpipes shall be installed prior to construction exceeding 40 feet in height above the lowest level of fire department vehicle access. B.Such standpipe shall be provided with fire department hose connections at accessible locations adjacent to usable stairways. C.Such standpipes shall be extended as construction progresses to within one floor of the highest point of construction having secured decking or flooring. FIRE PROTECTION SPECIFICATIONS 02/27/2025 10/24/2025 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE EXISTING SPRINKLER HEAD M02A RESTROOM M01 CORRIDOR M03 TENATE SPACE 2 M02 TENANT SPACE 1 2" SPRINKLER HEAD 2 1 - ATTIC SPACE DN 1 1 1 1 1 1 SPRINKLER HEAD POSSIBLE CONFLICT WITH MINIMUM CLEARANCE FROM TOP OF DEFLECTOR TO CEILING. VERIFY COMPLIANCE AFTER INSULATION WORK IS COMPLETE SPRINKLER HEAD POSSIBLE CONFLICT WITH MINIMUM CLEARANCE FROM TOP OF DEFLECTOR TO CEILING. VERIFY COMPLIANCE AFTER INSULATION WORK IS COMPLETE DUCT WORK WITHIN DORMER SPACE, NO SPRINKLER HEAD MODIFICATION REQUIRED SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 9/ 2 5 / 2 0 2 5 2 : 0 8 : 2 9 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 SPRINKLER DEMOLITION PLANS BAM YB Scale: 1/4"=1'-0" FIRST FLOOR DEMOLITION PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR DEMOLITION PLAN2 FPD-101 Scale: 3/16"=1'-0" ATTIC DEMOLITION PLAN3 1.ATTIC SPRINKLER SYSTEM SUSPECTED TO BE SERVED BY DRY VALVE WITHIN BASEMENT AT SPRINKLER SERVICE. 2.PROTECT ALL ATTIC SPRINKLER HEADS PRIOR TO INSULATION WORK. COVER AS REQUIRED. 3.ALL SPACES ARE SPRINKLERED PER NFPA 13-2016 REQUIREMENTS. SPRINKLER HEADS OUTSIDE SCOPE OF WORK NOT SHOWN. 4.AFTER ATTIC INSULATION WORK IS COMPLETED CONTRACTOR SHALL VERIFY ALL SPRINKLER HEADS IN ATTIC ARE MAINTAINED WITH LISTED CLEARANCE REQUIREMENTS. IF ANY SPRINKLER HEADS ARE FOUND OUT OF COMPLIANCE DEMOLISH HEAD PER KEY NOTE 1.DEMOLITION KEYNOTES NUMBER NOTES 1 ISOLATE SPRINKLER MAIN SERVING SPACE. DRAIN PIPING, AND DEMOLISH SPRINKLER HEAD. CAP FOR FUTURE CONNECTION. 2 DEMOLISH PIPING, CAP OPEN ENDS FOR FUTURE CONNECTION. FIRE PROTECTION GENERAL NOTES 1.ALL DEMO WORK THAT IMPACTS THE USE OF THE WHOLE BUILDING SHALL BE CONDUCTED ON SATURDAYS AND SUNDAYS IN ORDER TO MAINTAIN PROPER USE CASE OF THE BUILDING. DEMOLITION GENERAL NOTES 02/27/2025 10/24/2025 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR 4 M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM 2" 2 2 2 3 NEW HEAD 7.5' OFF OF NORTH WALL 2" 2" FROM BUILDING SPRINKLER SYSTEM OFFSET PIPE SO PIPING PASSES THROUGH WALL BETWEEN DOOR AND DIVIDING WALL, BETWEEN RESTROOM AND TENANT SPACE 2 2" NOTE: EXISTING SPRINKLERS IN THIS AREA NOT SHOWN. SPRINKLER PIPING SHOWN IN APPROXIMATE LOCATIONS. 2" 5 - ATTIC SPACE DN 1 1 1 1 1 1 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 9/ 2 5 / 2 0 2 5 2 : 0 8 : 3 3 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 SPRINKLER FLOOR PLANS BAM YB Scale: 1/4"=1'-0" FIRST FLOOR PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR PLAN2 FP-101 Scale: 3/16"=1'-0" ATTIC PLAN3 1.IF ADDITIONAL SPRINKLER HEADS ARE FOUND TO BE OUT OF COMPLIANCE PROVIDE NEW HEAD PER KEY NOTE 1. FIRE PROTECTION GENERAL NOTES KEYNOTES NUMBER NOTES 1 PROVIDE NEW UPRIGHT SPRINKLER HEAD AT ELEVATION TO MAINTAIN LISTED CLEARANCE REQUIREMENTS TO CEILING STRUCTURE. CONNECT TO EXISTING. 2 PROVIDE SIDE WALL SPRINKLER HEAD CONNECTING TO NEAREST PIPING BRANCH. PIPING SHALL BE MAINTAINED AT SAME ELEVATION AS EXISTING BRANCH. 3 PROVIDE UPRIGHT SPRINKLER HEAD CONNECTING TO NEAREST PIPING BRANCH. PIPING SHALL BE MAINTAINED AT SAME ELEVATION AS EXISTING BRANCH. 4 PROVIDE SEMI RECESSED PENDENT SPRINKLER HEAD CONNECTING TO NEAREST PIPING BRANCH. PIPING SHALL BE CONCEALED WITHIN CEILING SPACE. 5 INSTALL NEW PIPING A MINIMUM OF 0'-3" AWAY FROM WALL. 02/27/2025 10/24/2025 LEGEND & NOTES BAM YB LEGEND EXHAUST GRILLE RETURN GRILLE SUPPLY DIFFUSER FLEX DUCT VOLUME DAMPER FIRE DAMPER CONNECT TO EXISTING ROOM SENSORS CARBON DIOXIDE SENSORC NITROGEN DIOXIDE SENSORN OCCUPANCY SENSORO THERMOSTATT DEMOLISHED EXISTING TO REMAIN A.HEAT PUMP SYSTEMS: 1.1.During unoccupied periods as determined by 7 day programmable thermostat, the system shall be set back to adjustable setpoint temperatures. 1.2.During occupied periods as determined by 7 day programmable thermostat, the system shall respond to setpoint temperatures. Each fan coil shall have a thermostat for heating and cooling setpoints. The unit shall remain on until setpoint is reached. B.ELECTRIC WALL HEATER 1.1.Wall heater shall have an internal digital thermostat (set to 68 degrees F) with lockout that is to control setpoint temperatures. Upon a call for heat, the heater shall turn on and remain on. Upon setpoint being satisfied, the heater shall turn off and remain off. C.ENERGY RECOVERY VENTILATOR SYSTEMS: 1.1.ERV-1; Once enabled, the exhaust and outdoor air motorized dampers shall be open 100% and supply and exhaust fan shall run. The unit shall be enabled by a wall mounted CO2 sensor located in each space and setpoint reading over 700 ppm (adjustable) or a ceiling mounted occupancy sensor in each bathroom. Once the CO2 setpoint and occupancy sensors are satisfied the fan shall stop and the exhaust and outdoor air motorized dampers shall be closed. The unit shall have an electric resistance duct heater that the internal SRC controller shall control based on supply air temperature of 68 degrees F. SEQUENCE OF OPERATIONS 2020 IECC COMPLIANCE CODE SECTION COMPLIANCE C105.2.1 REFERENCE MECHANICAL AND PLUMBING DOCUMENTS FOR DUCT AND PIPE INSULATION MATERIALS, ARCHITECTURAL DOCUMENTS FOR ALL OTHER INSULATION MATERIALS C105.2.2 REFERENCE ARCHITECTURAL PLANS FOR FENESTRATION U-FACTORS AND SOLAR HEAT GAIN COEFFICIENTS C105.2.3 REFERENCE ARCHITECTURAL PLANS FOR AREA-WEIGHTED U-FACTORS AND SOLAR HEAT GAIN COEFFICIENTS C105.2.4 MECHANICAL DESIGN CONFORMS TO 2020IECC AND IMC CODE REQUIREMENTS C105.2.5 REFERENCE MECHANICAL AND PLUMBING DOCUMENTS FOR EQUIPMENT TYPES, SIZES AND EFFICIENCIES C105.2.7 REFERENCE MECHANICAL DOCUMENTS FOR EQUIPMENT AND SYSTEM CONTROLS C105.2.8 REFERENCE MECHANICAL DOCUMENTS FOR EQUIPMENT HORSEPOWER AND CONTROLS C105.2.9 REFERENCE MECHANICAL AND PLUMBING SPECIFICATIONS FOR SEALING AND INSULATION LOCATIONS C105.2.12 REFERENCE ARCHITECTURAL SPECIFICATIONS FOR AIR SEALING DETAILS C403.3.1 HVAC LOAD SIZING HAS BEEN PERFORMED IN THE CARRIER HAP PROGRAM, USING RTS (HEAT BALANCE METHODOLOGY C403.3.2 ALL HVAC EQUIPMENT MEETS OR EXCEEDS MINIMUM EFFICIENCIES, REFERENCE MECHANICAL DOCUMENTS C403.4 REQUIRED HVAC CONTROLS SHALL BE PROVIDED, REFERENCE MECHANICAL DOCUMENTS C403.5.3 ECONOMIZER CONTROL NOT REQUIRED. ALL INDIVIDUAL UNIT COOLING CAPACITIES ARE LESS THAN 270,000 BTU/HR C403.7.1 DEMAND CONTROL VENTILATION NOT REQUIRED PER EXCEPTION 3 C403.7.7 OUTDOOR AIR INTAKE AND EXHAUST OPENINGS AND STAIRWAY AND SHAFT VENTS SHALL BE PROVIDED WITH CLASS I MOTORIZED DAMPERS C403.11.1 DUCT IS REQUIRED TO BE INSULATED TO THE INDICATED MINIMUM LEVEL, REFERENCE MECHANICAL DOCUMENTS C403.11.2 INSTALLING CONTRACTOR SHALL ENSURE THAT ALL AIR DISTRIBUTION COMPONENTS ARE PROPERLY SEALED C403.11.3 ALL PIPING INSULATION CRITERIA HAS BEEN MET, REFERENCE MECHANICAL/PLUMBING DOCUMENTS C408.1.1 OPERATION AND MAINTENANCE MANUAL SHALL BE PROVIDED TO OWNER BY CONTRACTOR FOR ALL EQUIPMENT C408.2 MECHANICAL COMMISSIONING IS NOT REQUIRED C408.2.2 INSTALLING CONTRACTOR SHALL TEST AND BALANCE ALL HVAC SYSTEMS AND PROVIDE REPORT TO ENGINEER M-001 AIR TERMINAL SCHEDULE TYPE MANUFACTURER MODEL DESCRIPTION COLOR AIR QUANTITY (CFM)ARRANGEMENT NOISE CRITERIA (MAX dB)NECK SIZE QUANTITY COMMENTS A BROAN 641 EXHAUST NATURAL ALUMINUM 90 WALL NA 6"1 NA B BROAN 641FA OUTDOOR AIR NATURAL ALUMINUM 90 WALL NA 6"1 NA C TITUS 23R RETURN WHITE 40 CEILING 12 6X6 1 PROVIDE MOUNTING FRAME D TITUS 23R RETURN WHITE 50 CEILING 12 6X6 1 PROVIDE MOUNTING FRAME E TITUS 111RL SUPPLY WHITE 60 CEILING 11 6X6 1 PROVIDE MOUNTING FRAME F TITUS 111RL SUPPLY WHITE 30 CEILING 11 6X6 1 PROVIDE MOUNTING FRAME FAN COIL SCHEDULE TYPE MANUFACTURER MODEL DESCRIPTION AIR FLOW CFM ESP, in. WC COOLING BTU/HR HEATING LENGTH WIDTH HEIGHT WEIGHT, lbs ELECTRICAL COMMENTSTOTALBRU/HR VOLTAGE PHASE MCA FC-1 LG LSN181HSV5 WALL MOUNTED FAN COIL 558 44 18,000 21,600 3'-3 9/32"0'-8 9/32"1'-1 19/32"25.6 208 1 0.4 PROVIDE ASPEN MINI AQUA CONDENSATE PUMP FC-2 LG LSN090HSV5 WALL MOUNTED FAN COIL 268 36 9,000 10,900 2'-8 15/16"0'-7 7/16"1'-0 1/8"18.3 208 1 0.4 PROVIDE ASPEN MINI AQUA CONDENSATE PUMP HEAT PUMP SCHEDULE TYPE MANUFACTURER MODEL DESCRIPTION COOLING HEATING LENGTH WIDTH HEIGHT WEIGHT, LBS ELECTRICAL COMMENTSTOTAL BTU/HR CAPACITY BTU/HR VOLTAGE PHASE MCA HP-1 LG LMU361HHV 3.0 TON HEAT PUMP 47,000 50,000 3'-1 13/32"1'-3 11/32"4'-6 11/32"218 208 1 32.7 PROVIDE QUICK SLING STAND, LG PMBD3620 BRANCH BOX (BB-1). FURNISH DISCONNECTS. ENERGY RECOVERY VENTILATOR SCHEDULE TYPE MANUFACTURER MODEL DESCRIPTION AIR FLOW CFM SUPPLY ESP, in. WC WEIGHT, LBS DIMENSIONS ELECTRICAL COMMENTSLENGTH (in)WIDTH (in)HEIGHT (in)VOLTAGE PHASE MCA ERV-1 RENEWAIRE EV PREMIUM S INDOOR ENERGY RECOVERY VENTILATOR 130 0.10 32 30 22 15 120 1 15 PROVIDE 2 kW DUCT HEATER & MERV 8 FILTERS ELECTRIC HEATER SCHEDULE TYPE MANUFACTURER MODEL CFM KW LENGTH (in)WIDTH (in)HEIGHT (in)VOLTAGE PHASE EH-1 QMARK SSHO4008 100 1.8-4.0 20 16 6 208 1 EH-2 STIEBEL ELTRON CNS 100-1 PLUS 1 18 17 4 120 1 PIPE INSULATION THICKNESS SCHEDULE FLUID OPERATING TEMPERATURE RANGE (°F) INSULATION CONDUCTIVITY NOMINAL PIPE SIZE CONDUCTIVITY BRU*in/(hr*FT²*°F) MEAN RATING TEMPERATURE (°F) <1 1 TO < 1 1/2 1 1/2 TO < 4 4 TO < 8 ≥8 105 - 140 0.21 - 0.28 100 1.0 1.0 1.5 1.5 1.5 NOTES: 1. FOR EXTERIOR PIPING, PROVIDE ADDITIONAL PROTECTIVE UV PIPE INSULATION. UV PAINT ON TOP OF PIPE INSULATION IS NOT ACCEPTABLE. 2. PROVIDE FACTORY APPLIED ASJ FOR ALL FIBERGLASS PIPE INSULATION. 3. PROVIDE VAPOR BARRIER ON ALL SYSTEMS OPERATING BELOW AMBIENT TEMPERATURE. SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 5 2 : 2 1 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 23 31 32 10/24/2025 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 1 1 1 2 3 3 3 EXISTING PIPING M02A RESTROOM M01 CORRIDOR M03 TENATE SPACE 2 M02 TENANT SPACE 1 444 4 5 NOTE: REMOVE ABANDONED PIPES ON THE NORTH AND EAST WALL. GC TO PATCH AND FINISH. (TYP.) EXISTING PIPING DEMOLISH BRANCH BACK TO MAIN DEMOLISH BRANCH BACK TO MAIN DEMOLISH BRANCH BACK TO MAIN MECHANICAL DEMOLITION PLANS BAM YB Scale: 1/4"=1'-0" FIRST FLOOR DEMOLITION PLAN2 Scale: 1/4"=1'-0" MEZZANINE FLOOR DEMOLITION PLAN3 MD-101 Scale: 1/4"=1'-0" BASEMENT DEMOLITION PLAN1 DEMOLITION KEYNOTES NUMBER NOTES 1 DEMOLISH HYDRONIC RADIATORS IN BATHROOMS. DRAIN AND DEMOLISH BRANCH PIPING. RECONNECT PIPING INTO LOOP TO ENSURE HYDRONIC LOOP IS OPERATIONAL AND HYDRONIC RADIATORS IN OFFICES 109 & 110 REMAIN OPERATIONAL. DEMOLISH THERMOSTATS, SOLENOID VALVES AND DISCONNECT FROM CENTRAL BMS SYSTEM. REPROGRAM AS REQUIRED. 2 ERV EXHAUST IN SPACE TO REMAIN. REPROGRAM AS REQUIRED. 3 CLOSE ISOLATION VALVES IN BASEMENT BELOW FOR HYDRONIC RADIATORS (4 IN TOTAL) IN OFFICE 107, OFFICE 109, OFFICE 110 AND RESTROOM 106. DRAIN AND DEMOLISH BRANCH PIPING. STORE RADIATORS AND BRANCH PIPING FOR REINSTALLATION. REPROGRAM AS REQUIRED. 4 DEMOLISH HYDRONIC RADIATORS IN TENANT SPACE 1 M02, RESTROOM M02A AND TENANT SPACE 2 M03. DRAIN AND DEMOLISH BRANCH PIPING. RECONNECT REMAINING PIPING INTO LOOP TO ENSURE HYDRONIC LOOP IS OPERATIONAL. DEMOLISH THERMOSTATS, SOLENOID VALVES AND DISCONNECT FROM CENTRAL BMS SYSTEM. REPROGRAM AS REQUIRED. 5 DEMOLISH THROUGH WALL EXHAUST FAN IN RESTROOM M02A. MECHANICAL DEMOLITION NOTES 1.ALL DEMO WORK THAT IMPACTS THE USE OF THE WHOLE BUILDING SHALL BE CONDUCTED ON SATURDAYS AND SUNDAYS IN ORDER TO MAINTAIN PROPER USE CASE OF THE BUILDING. 2.DEMOLISH ALL ABANDONED PIPING WITHIN FIRST FLOOR AND MEZZANINE SPACE. GC TO PATCH ALL WALL, FLOOR AND CEILING PENETRATIONS, COORDINATE ALL LOCATIONS WITH GENERAL CONTRACTOR. SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 5 2 : 3 8 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 24 31 32 10/24/2025 105 CORRIDOR 3 STAIR 101 111 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR 2 1 1 22 EH-1 EH-1 EXISTING PIPING M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM 3 33 4 5 FC-2FC-1 AIR TERMINAL "F" 30 CFMAIR TERMINAL "D" 50 CFM AIR TERMINAL "C" 40 CFM AIR TERMINAL "E" 60 CFM EH-2 T T C CO EXISTING PIPING - ATTIC SPACE DNERV-1 6" SUPPLY 4" SUPPLY 5" SUPPLY DOWN TO TERMINAL "E" 6" RETURN 5" RETURN DOWN TO TERMINAL "C" 5" RETURN 5" RETURN DOWN TO TERMINAL "D" 4" SUPPLY DOWN TO TERMINAL "F" 6" OA 6" SUPPLY EXHAUST TERMINAL "A" 90 CFM 6 OUTDOOR AIR TERMINAL "B" 90 CFM 6 BB-1 FOR HP-1/FC-1, FC-2 7 7 7 7 7 7 7 7 7 7 7 MECHANICAL FLOOR PLANS BAM YB Scale: 1/4"=1'-0" FIRST FLOOR PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR PLAN2 Scale: 1/8"=1'-0" ATTIC PLAN3 M-101 KEYNOTES NUMBER NOTES 1 PROVIDE EH-1 BELOW WINDOW RECESSED INTO FURRED OUT WALL. GENERAL CONTRACTOR TO PROVIDE FURRED OUT WALL AND CUT OUT FOR WALL HEATER. 2 LOCATE RADIATORS IN EXISTING LOCATIONS SHIFTED OUT AGAINST NEW FURRED OUT WALL. SUPPLY AND RETURN PIPING SHALL EXTEND FROM BASEMENT THROUGH FURRED OUT WALL TO CONNECT TO RADIATORS. 3 2" DOOR UNDERCUT PROVIDED BY GENERAL CONTRACTOR. 4 PLACE FAN COIL OVER AND CENTERED BETWEEN WINDOWS. INSTALL FAN COIL TO MANUFACTURER'S SUPPLIED MOUNTING PANEL PER MANUFACTURER'S INSTALLATION REQUIREMENTS. 5 PLACE FAN COIL OVER AND CENTERED ON WINDOW. INSTALL FAN COIL TO MANUFACTURER'S SUPPLIED MOUNTING PANEL PER MANUFACTURER'S INSTALLATION REQUIREMENTS. 6 CENTER AIR TERMINAL IN WINDOW OPENING. INFILL WINDOW AROUND AIR TERMINAL TO MATCH EXISTING ERV AIR TERMINAL INFILL. 7 SUPPORT ERV FROM ROOF RAFTER ABOVE WITH 3/8" CORROSION RESISTANT STEEL THREADED ROD CONNECTED TO UNISTRUT MOUNTED ON ROOF JOISTS. PROVIDE VIBRATION DAMPENING CONNECTIONS AT UNISTRUT AND EQUIPMENT CONNECTIONS. ALL DUCTWORK SHALL BE HUNG FROM DUCT SUPPORTS FASTENED TO ROOF RAFTER. NOT TO SCALE ROOF PLAN4 MECHANICAL GENERAL NOTE: 1.CONNECT CONDENSATE INTO CONDENSATE MAIN PROVIDED BY PLUMBING CONTRACTOR. 2.REPROGRAM CENTRAL BMS SYSTEM AT ALL HYDRONIC LOOP LOCATIONS REMOVED FROM BUILDING AS REQUIRED. REFER TO KEYNOTES 1 AND 4 ON MD-101. 3.SEAL ALL WALL, CEILING AND FLOOR PENETRATIONS. REFER TO ARCHITECTURAL DRAWINGS AND SPECIFICATIONS FOR MORE INFORMATION. GENERAL CONTRACTOR TO PATCH AND FINISH. HP-1 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 5 2 : 3 4 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 5 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 NOTE: ROOF APPROXIMATELY 25'-0" AFG 02/27/2025 25 31 32 10/24/2025 HEAT PUMP EQUIPMENT STAND ROOF FASTEN LEGS TO SLEEPERS. DO NOT PENETRATE ROOF MEMBRANE. 2 LAYERS OF 1" (5/4) PLASTIC COMPOSITE SLEEPERS, 40" LONG x 12" WIDE SCHEMATICS & DETAILS BAM YB M-401 NOT TO SCALE PIPING DIAGRAM1 NOT TO SCALE HEAT PUMP STAND DETAIL2 LMU361HHV Additional Refrigerant : 0.83 lbs (Precharged Refrigerant : 11.46 lbs) (25.40 kBtu/h)(16.29/29.88 kBtu/h) PMBD36203/8 : 3/4 50.0 ft LSN181HSV5 #Mezzanine Large (16.97/13.34 kBtu/h)(10.88/19.96 kBtu/h) 1/4 : 1/2 30.0 ft LSN090HSV5 #Mezzanine Small (8.43/6.63 kBtu/h)(5.41/9.92 kBtu/h) 1/4 : 3/8 30.0 ft HP-1 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 5 2 : 3 0 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 26 31 32 10/24/2025 LOWERCASE INDICATES SWITCHING d CIRCUIT BREAKER PANEL - REPLACE NL D "NL" INDICATES NIGHT LIGHT UPPERCASE INDICATES TYPE LIGHT FIXTURE CIRCUIT BREAKER PANEL - NEW WALL MOUNTED FIXTURE CEILING MOUNTED FIXTURE DUPLEX RECEPTACLE SWITCH 3-WAY3 OS WALL MOUNTED EXIT LIGHT OCCUPANCY SENSOR JUNCTION BOX WP GROUND FAULT CIRCUIT INTERRUPTER WEATHERPROOF HOME RUN GF J SAFETY SWITCH - UNFUSED EMERGENCY FIXTURE S R SMOKE DETECTOR DUCT SMOKE DETECTOR HEAT DETECTOR (ROR) FIRE ALARM HORN/STROBE D S HD SUPPLY DUCT RETURN DUCT CIRCUIT BREAKER PANEL - EXISTING SAFETY SWITCH - FUSED AC/BC ABOVE/BELOW COUNTER D DIMMING QUADRUPLEX RECEPTACLE J F RJ45 DATA JACK SWITCH - EXISTING LEGEND DEMOLISH OS OCCUPANCY SENSOR # #NUMBER OF DATA JACKS GENERAL NOTES: 1.ALL NEW WIRING, EXCEPT IN MECHANICAL AND UTILITY SPACES, SHALL BE CONCEALED UNLESS NOTED OTHERWISE. 2.ALL COMMUNICATIONS WORK SHALL BE TESTED, CERTIFIED, AND DOCUMENTED. LABEL ALL WALL PLATES AND COMMUNICATION ROOM TERMINATIONS WITH PERMANENT LABELS. 3.SUPPORT ALL WIRING BY THE BUILDING STRUCTURE USING DEVICES MANUFACTURED SPECIFICALLY FOR THE INTENDED USE. ALL WIRING SHALL BE ARRANGED TO PERMIT REMOVAL OF CEILING TILES AND ACCESS TO ALL EQUIPMENT. 4.PROVIDE DISCONNECTS FOR ALL EQUIPMENT AS REQUIRED BY NEC, UNLESS FURNISHED WITH SPECIFIED EQUIPMENT. INSTALL DISCONNECTS WHEN FURNISHED WITH EQUIPMENT. 5.DEVICE HEIGHT ABOVE FINISH FLOOR TO CENTER (UNLESS OTHERWISE NOTED): RECEPTACLE - 18" WIREMOLD - 18" VOICE/DATA - 18" WALL TELEPHONE - 60" SWITCH - 48" EMERGENCY LIGHT - 84" HORN/STROBE - 84" PULL STATION - 48" LEGENDS & NOTES YB LIGHTING FIXTURE SCHEDULE PROVIDE AS SPECIFIED OR APPROVED EQUAL MARK ITEM MANUF MODEL DESCRIPTION LAMP NOTES A 2' X 2' SURFACE FIXTURE HE WILLIAMS LT-22-L39-835-AF/12W 2' X 2' SURFACE MOUNT DIRECT/INDIRECT DROP BASKED FIXTURE, 3900 LUMENS, 80 CRI, 3500K LED AE 2' X 2' SURFACE FIXTURE HE WILLIAMS LT-22-L39-835-AF-EM/12W 2' X 2' SURFACE MOUNT DIRECT/INDIRECT DROP BASKED FIXTURE, 3900 LUMENS, 80 CRI, 3500K, WITH BATTERY BACKUP LED WITH BATTERY BACKUP B 6" X 2' SURFACE FIXTURE FINELITE HP-6-SM-D-835-F-96LG-120 6" X 1' SURFACE MOUNT, 5200 LUMENS, 80 CRI, 3500K LED BE 6" X 2' SURFACE FIXTURE FINELITE HP-6-SM-D-835-F-96LG-120-LGD10W 6" X 1' SURFACE MOUNT, 5200 LUMENS, 80 CRI, 3500K LED WITH BATTERY BACKUP C 2' X 2' SURFACE FIXTURE HE WILLIAMS LT-22-L39-835-AF/12W 2' X 2' SURFACE SURFACE MOUNT DIRECT/INDIRECT DROP BASKED FIXTURE, 3900 LUMENS, 80 CRI, 3500K LED LT-22-SMK-W CE 2' X 2' SURFACE FIXTURE HE WILLIAMS LT-22-L39-835-AF-EM/12W 2' X 2' SURFACE MOUNT DIRECT/INDIRECT DROP BASKED FIXTURE, 3900 LUMENS, 80 CRI, 3500K, WITH BATTERY BACKUP LED LT-22-SMK-W; WITH BATTERY BACKUP X1 EXIT SIGN THE EXIT LIGHT CO.LEDT-R-W-BB WALL MOUNTED EXIT SIGN LED WITH BATTERY BACKUP 2020 IECC COMPLIANCE CODE SECTION COMPLIANCE C405.2 LIGHTING CONTROL CRITERIA HAVE BEEN MET, REFER TO LIGHTING SCHEDULE NOTES C405.6 ELECTRICAL POWER HAS BEEN PROVIDED PER CODE E-001 EQUIPMENT CONNECTION SCHEDULE UNIT NO.LOCATION VOLTS / PHASE UNIT M.C.A.UNIT MOCP VA PANEL HP-1 ROOF 208/1 32.7 50 6801 M-1,3 ERV-1 ATTIC 120/1 15 20 1800 M-9 BB-1 ATTIC 208/1 0.08 20 16 M-12,14 FC-1 MEZZANINE 208/1 0.4 20 8.5 M-15,17 FC-2 MEZZANINE 208/1 0.4 20 8.5 M-15,17 EH-1 1ST FLOOR 208/1 14.4 20 3000 Existing Panel A EH-2 MEZZANINE 120/1 8.3 20 1000 M-11 WH-1 MEZZANINE 120/1 29 40 3500 M-16 DUCT HEATER ATTIC 120/1 16.7 25 2000 M-2 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 5 : 4 6 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 5 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 1.PROVIDE SUBMITTAL FOR EACH LIGHT FIXTURE FOR REVIEW BY OWNER AND ENGINEER. 2.FOR ANY SUBMITTED FIXTURE WITH SCREW-IN LAMPS, EC SHALL PROVIDE LED LAMPS AS APPROVED BY OWNER AND ENGINEER. 3.ALL LIGHTING IN COMMON AREAS TO BE 3000K, UNLESS OTHERWISE NOTED. 1.ALL OCCUPANCY/VACANCY SENSORS SHALL BE MANUALLY ADJUSTED TO EXTINGUISH LIGHTS AFTER A PERIOD OF 15 MINUTES OF INACTIVITY. 2.STAIRWELL LIGHT FIXTURES HAVE INTEGRATED MOTION SENSORS. REFER TO LIGHT FIXTURE SCHEDULE FOR CONTROL SETTINGS. 3.OCCUPANCY SENSORS SHALL CONTROL ALL HALL OR ROOM LIGHTING, UNLESS OTHERWISE NOTED. WHERE FIXTURES ARE TO REMAIN CONSTANTLY ILLUMINATED, UNOCCUPIED LIGHTING LEVELS SHALL BE 20% OF OCCUPIED LEVELS. 4.ALL EMERGENCY LIGHTING AND EXIT SIGNAGE SHALL HAVE INTEGRAL BATTERY BACKUP. 5.LIGHTS DESIGNATED WITH "E" ARE EMERGENCY FIXTURES, REFER TO LIGHTING SCHEDULE 6.CONTROL OF EXTERIOR LIGHTING, EGRESS AND SITE LIGHT FIXTURES SHALL HAVE DAYLIGHT SHUTOFF. LIGHTING FIXTURE SCHEDULE NOTES LIGHTING CONTROL NOTES MLM 02/27/2025 27 3132 10/24/2025 106 RESTROOM 104 RESTROOM 103 RESTROOM 102 CORRIDOR 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE OS M02A RESTROOM M01 CORRIDOR M03 TENATE SPACE 2 M02 TENANT SPACE 1 ELECTRICAL DEMOLITION PLANS MLM YB Scale: 1/4"=1'-0" FIRST FLOOR DEMOLITION PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR DEMOLITION PLAN2 ED-101 1.ALL DEMO WORK THAT IMPACTS THE USE OF THE WHOLE BUILDING SHALL BE CONDUCTED ON SATURDAYS AND SUNDAYS IN ORDER TO MAINTAIN PROPER USE CASE OF THE BUILDING. 2.REMOVE ALL ELECTRICAL LIGHTING AND POWER DEVICES BACK TO SOURCE. CIRCUIT BREAKERS TO BE LABELED AS SPARE WITHIN THE PANEL. 3.CONTRACTOR TO VERIFY THAT THE SURFACE MOUNTED RACEWAY TO THE ATTIC IS INDEED LIVE. IF IT IS LIVE, DISCONNECT DURING DEMOLITION AND RESTORE THE CONNECTION TO THE ATTIC DURING CONSTRUCTION. 4.PROVIDE TEMPORARY POWER TO ABATEMENT CONTRACTOR. ELECTRICAL DEMOLITION NOTES SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 5 : 5 6 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 28 3132 10/24/2025 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR EXIST. PANEL 'A' EH-1 EH-1 7 PANEL 'A' 34,36; 20A BREAKER PANEL 'A' 38,40; 20A BREAKER AC GFI 7 7 8 J J J 8 J 11 J 10 J 4 4 J 8 12 12 14 48" AFF TO TOP OF DEVICE 48" AFF TO TOP OF DEVICE 48" AFF TO TOP OF DEVICE 2 2 2 2 14 14 M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM AC GFCI (N) PANEL M 100A/3PH 120/208V EH-2 FC-1 M-21 M-20 M-15,17 M-11 M-25 M-23 M-4 M-23 52 J 4 M-22 1 M-4 M-4 M-23 M-20 M-20 M-21 M-21 FC-2 M-15,17WH-1 M-16 9 9 J J J 3 13 2 2 2 2 22 2 ELECTRICAL CLOSET BOILER ROOM HVAC HVAC SWBD 3 STUB UP NEW CONDUIT AND ROUTE TOWARDS NEW LOCATION OF PANEL 'M' ON MEZZANINE FLOOR IT ROOM IS TO THE EAST OF HALLWAY (NOT SHOWN) OLD PHONE ROOM ELECTICAL FLOOR PLANS YB Scale: 1/4"=1'-0" FIRST FLOOR PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR PLAN2 MLM E-101 KEYNOTES NUMBER NOTES 1 POWER FOR DATA RACK 2 TERMINATE MEZZANINE CAT6A CABLES IN THIS ROOM. 3 SUPPLY 2-INCH CONDUIT EQUIPPED WITH (4) #3 WIRES TO CONNECT FROM THE SWITCHBOARD LOCATED IN THE BASEMENT ROUTING UP THROUGH ATTIC WALL AND THEN DOWN TO NEW PANEL 'M' LOCATED ON THE MEZZANINE LEVEL. UTILIZE EXISTING 100A SPARE IN SWITCHBOARD. 4 PULL CAT6A WIRE FOR FUTURE CAMERA CONNECTION BACK TO BASEMENT IT ROOM. COIL UP ON BOTH ENDS FOR FUTURE CONNECTION. TERMINATE INTO BOX WITH RJ45 CONNECTION AND FACEPLATE. COORDINATE EXACT LOCATION WITH THE OWNER. 5 PROVIDE (1) 2" CONDUIT AND CAT6A FROM BASEMENT OLD PHONE ROOM TO DATA RACK LOCATED ON MEZZANINE LEVEL. 6 NOT USED 7 TIE NEW GENERAL POWER INTO EXISTING RECEPTACLES. 8 ELECTRICIAN TO INSTALL 18-4 STRANDED WIRE WITHIN DOOR FRAME TO STRIKE LOCATION. ELECTRICIAN TO INSTALL 22-6 STRANDED WIRE FROM CONTROL PANEL IN BASEMENT IT ROOM TO JUNCTION BOX LOCATED ADJACENT TO DOOR FOR PROXIMITY SENSOR (PROXIMITY SENSOR BY OTHERS). COORDINATE WITH OWNER. 9 INSTALL NEW SURFACE RACEWAY AND ELECTRICAL BOXES. 10 PROVIDE POWER FOR DOOR OPERATOR. ELECTRICIAN TO INSTALL 22-6 STRANDED WIRE FROM OPERATOR TO CONTROL PANEL LOCATED IN BASEMENT IT ROOM. 11 JUNCTION BOX ON TOP OF COUNTER FOR ACCESS CONTROL. ELECTRICIAN TO INSTALL 18-4 STRANDED WIRE FROM JUNCTION BOX TO CONTROL PANEL IN BASEMENT IT ROOM. DESIGN INTENT IS FOR ACCESS CONTROL TO UNLOCK DOOR 105-1. COORDINATE FINAL LOCATION WITH OWNER. 12 ADA ACTUATOR (BUTTON) FOR DOOR OPERATION, REFER TO ARCHITECTURAL DRAWINGS FOR EXACT LOCATION AND MODEL NUMBER. ELECTRICIAN TO CONNECT ADA ACTUATOR (BUTTON) TO DOOR OPERATOR. PUSH BUTTON LOCATED WITHIN OFFICE 107 TO BOTH UNLATCH ELECTRIC STRIKE AND OPEN DOOR. MOUNT PER MANUFACTURER'S INSTRUCTIONS. 13 ELECTRICAL CONTRACTOR RESPONSIBLE FOR PROVIDING TEMPORARY POWER FOR ABATEMENT CONTRACTOR. 14 ALL FIRST FLOOR DATA TO TERMINATE IN BASEMENT IT ROOM. Scale: 1/8"=1'-0" BASEMENT PLAN3 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 6 : 0 7 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 29 3132 10/24/2025 DN ERV-1 BB-1 HP-1 M-6 M-9 M-12,14 M-1,3 M-6 M-6 ELECTICAL FLOOR PLAN & SCHEMATIC YBMLM E-102 Scale: 1/8"=1'-0" ATTIC/ROOF PLAN1 (N) PANEL M 100A/3PH 120/208V SWITCHBOARD EXISTING BASEMENT MEZZANINE (4) #3 IN 2-INCH CONDUIT APPROXIMATELY 100'-0" EXISTING NOT TO SCALE PARTIAL ELECTRICAL SINGLE LINE DIAGRAM2 1ST FLOOR SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 6 : 0 3 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 5 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 IT CLOSET - TENANT SPACE 1TENANT SPACE 1 TENANT SPACE 2 ATTIC 02/27/2025 30 3132 10/24/2025 105 CORRIDOR 3 STAIR 101 LOBBY 111 TOWN BOARD/COURTROOM 108 CORRIDOR 109 OFFICE 110 OFFICE 107 OFFICE 104 RESTROOM 103 RESTROOM 102 CORRIDOR AE AE AE AE AE AE AE AE A A A A A A A AE X1 X1 NOTE: ALL LIGHTING SHOWN ON THIS PLAN TO BE CIRCUITED TO EXISTING PANEL A. M03 TENANT SPACE 2 M02 TENANT SPACE 1 M01 CORRIDOR M02A RESTROOM CE C C CC CE CE CE C C B BE CE X1X1 X1 NOTE: ALL LIGHTING SHOWN IN THIS PLAN TO BE CIRCUITED TO PANEL M. Scale: 1/4"=1'-0" FIRST FLOOR PLAN1 Scale: 1/4"=1'-0" MEZZANINE FLOOR PLAN2 LIGHTING & FIRE ALARM FLOOR PLANS YBMLM E-111 1.LOCATION OF EXISTING HEAT DETECTORS IN THE ATTIC MAY INTERFERE WITH THE INSTALLATION OF THE ATTIC INSULATION. IF REQUIRED, CONTRACTOR SHALL DISCONNECT AND RECONNECT HEAT DETECTORS. FIRE ALARM NOTES SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 5 : 5 2 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 02/27/2025 31 31 32 10/24/2025 PANEL SCHEDULES YBMLM E-601 SHEET OF SHEET NUMBER SHEET TITLE PROJECT NUMBER PROJECT NORTH CONSULTANT It is a violation of the New York State Education Law, Article 145 Sec. 7209, for any person unless he is acting under the direction of a licensed professional Architect, Engineer or Land Surveyor to alter an item in any way. If an item bearing the seal of an Architect, Engineer or Land Surveyor is altered, the altering Architect, Engineer or Land Surveyor shall affix to the item his seal and the notation "altered by" followed by his signature and the date of such alteration, and a specific description of the alteration. PROJECT 2/ 2 6 / 2 0 2 5 1 : 3 5 : 5 9 P M /CH R I S B A C A Fax (315) 487 - 5947 Tel (315) 488 - 0377 215 Wyoming Street info@bellandspina.com www.bellandspina.com Fax (585) 487 - 9532 Suite 200 Tel (585) 200 - 5038 1163 Pittsford-Victor Rd DATEMARK DESCRIPTION The Contractor shall verify all dimensions and notify the Architect in writing of any discrepancies. All drawings and specifications are the property of the Architect and shall be used only on the job designated. CHECKED SCALE DRAWN DATE AS NOTED Syracuse, NY 13204 Pittsford, NY 14534 Suite 201 0 25 716-23-002 TO W N O F I T H A C A 2 N D F L . M E Z Z A N I N E & C O U R T O F F I C E R E N O V A T I O N TO W N O F I T H A C A T O W N H A L L 21 5 N O R T H T I O G A S T R E E T IT H A C A , N Y Cl i e n t P r o j e c t N o : BID DOCUMENTS 110 SOUTH ALBANY STREET ITHACA, NEW YORK 14850 PH: 607-277-1118 1. BOLD REPRESENTS NEW CIRCUIT BREAKER. Notes: Total Est. Demand Current:157 A Total Conn. Current:157 A Total Est. Demand:56675 VA Total Conn. Load:56675 VA Load Classification Connected Load Demand Factor Estimated Demand Panel Totals Legend: Total Amps:158 A 160 A 155 A Total Load:18.93 KVA 19.13 KVA 18.63 KVA 41 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 42 39 EXISTING 20 A 1 1.2 2.0 ------40 37 EXISTING 20 A 1 1.2 2.0 2 30 A (N) EH-1 38 35 EXISTING 20 A 1 1.2 2.0 ------36 33 EXISTING 20 A 1 1.2 2.0 2 30 A (N) EH-1 34 31 EXISTING 20 A 1 1.2 1.93 ------32 29 EXISTING 20 A 1 1.2 1.93 ------30 27 EXISTING 20 A 1 1.2 1.93 3 20 A EXISTING 28 25 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 26 23 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 24 21 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 22 19 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 20 17 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 18 15 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 16 13 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 14 11 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 12 9 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 10 7 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 8 5 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 6 3 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 4 1 EXISTING 20 A 1 1.2 1.2 1 20 A EXISTING 2 CKT Circuit Description Trip Poles A B C Poles Trip Circuit Description CKT Notes: Enclosure:NEMA 1 Mounting:Recessed Wires:4 Mains Rating:200 A Supply From:Phases:3 Mains Type:MCB Location:CORRIDOR 108 Volts:120/208 Wye A.I.C. Rating:22K Branch Panel:A Notes: Total Est. Demand Current:65 A Total Conn. Current:65 A Total Est. Demand:23526 VA Total Conn. Load:23526 VA Load Classification Connected Load Demand Factor Estimated Demand Panel Totals Legend: Total Amps:68 A 112 A 27 A Total Load:7.5 KVA 12.8 KVA 3.3 KVA 29 SPACE --1 ----1 --SPACE 30 27 SPACE --1 ----1 --SPACE 28 25 RESTROOM - MEZZ FLOOR 20 A 1 0.12 0 1 20 A SPARE 26 23 TENANT SPACE 2 RECs 20 A 1 0.9 0 1 20 A LIGHTING - TENANT SPACE 1 & 2 24 21 TENANT SPACE 1 RECs 20 A 1 1.2 1.6 1 20 A DATA RACK 22 19 SPARE 20 A 1 0 1.2 1 20 A TENANT SPACE 2 RECs 20 17 ------0.08 0 1 20 A SPARE 18 15 FC-1, FC-2 20 A 2 0.08 3.5 1 40 A WH-1 16 13 SPARE 20 A 1 0 0.8 ------14 11 EH-2 20 A 1 1.0 0.8 2 20 A BB-1 12 9 ERV-1 20 A 1 1.8 0 1 20 A SPARE 10 7 SPARE 20 A 1 0 0 1 20 A SPARE 8 5 SPARE 20 A 1 0 0.54 1 20 A 6 3 ------3.4 1.2 1 20 A TENANT SPACE 2 RECs 4 1 HP-1 50 A 2 3.4 2.0 1 25 A DUCT HEATER 2 CKT Circuit Description Trip Poles A B C Poles Trip Circuit Description CKT Notes: Enclosure:NEMA 1 Mounting:SURFACE Wires:4 Mains Rating:100 A Supply From:Phases:3 Mains Type:MCB Location:I.T.CLOSET - TENANT SPACE 1 Volts:120/208 Wye A.I.C. Rating:22K Branch Panel:M MLOSWITCHBOARD ROOF GENERAL RECs SWITCHBOARD Other 8000 VA 100%8000 VA Other 16766 VA 100%16766 VA Receptacle 48675 VA 100%48675 VA Receptacle 6760 VA 100%6760 VA 02/27/2025 31 3232 10/24/2025